Unmodified official OCDS data retained by Tenderline for this procurement process.
Complete current OCDS release JSON
{
"id": "000136-2021",
"tag": [
"award",
"contract"
],
"bids": {
"statistics": [
{
"id": "1",
"value": 7,
"measure": "bids",
"relatedLot": "1"
},
{
"id": "6",
"value": 9,
"measure": "bids",
"relatedLot": "2"
},
{
"id": "11",
"value": 8,
"measure": "bids",
"relatedLot": "5"
},
{
"id": "16",
"value": 3,
"measure": "bids",
"relatedLot": "6"
},
{
"id": "21",
"value": 4,
"measure": "bids",
"relatedLot": "7"
},
{
"id": "26",
"value": 5,
"measure": "bids",
"relatedLot": "8"
},
{
"id": "31",
"value": 3,
"measure": "bids",
"relatedLot": "9"
},
{
"id": "36",
"value": 5,
"measure": "bids",
"relatedLot": "10"
},
{
"id": "41",
"value": 4,
"measure": "bids",
"relatedLot": "11"
},
{
"id": "46",
"value": 3,
"measure": "bids",
"relatedLot": "12"
},
{
"id": "51",
"value": 5,
"measure": "bids",
"relatedLot": "14"
},
{
"id": "56",
"value": 7,
"measure": "bids",
"relatedLot": "16"
},
{
"id": "61",
"value": 5,
"measure": "bids",
"relatedLot": "13"
},
{
"id": "66",
"value": 9,
"measure": "bids",
"relatedLot": "15"
},
{
"id": "71",
"value": 6,
"measure": "bids",
"relatedLot": "3"
},
{
"id": "2",
"value": 7,
"measure": "smeBids",
"relatedLot": "1"
},
{
"id": "7",
"value": 9,
"measure": "smeBids",
"relatedLot": "2"
},
{
"id": "12",
"value": 8,
"measure": "smeBids",
"relatedLot": "5"
},
{
"id": "17",
"value": 3,
"measure": "smeBids",
"relatedLot": "6"
},
{
"id": "22",
"value": 4,
"measure": "smeBids",
"relatedLot": "7"
},
{
"id": "27",
"value": 3,
"measure": "smeBids",
"relatedLot": "8"
},
{
"id": "32",
"value": 3,
"measure": "smeBids",
"relatedLot": "9"
},
{
"id": "37",
"value": 4,
"measure": "smeBids",
"relatedLot": "10"
},
{
"id": "42",
"value": 4,
"measure": "smeBids",
"relatedLot": "11"
},
{
"id": "47",
"value": 3,
"measure": "smeBids",
"relatedLot": "12"
},
{
"id": "52",
"value": 4,
"measure": "smeBids",
"relatedLot": "14"
},
{
"id": "57",
"value": 6,
"measure": "smeBids",
"relatedLot": "16"
},
{
"id": "62",
"value": 4,
"measure": "smeBids",
"relatedLot": "13"
},
{
"id": "67",
"value": 9,
"measure": "smeBids",
"relatedLot": "15"
},
{
"id": "72",
"value": 6,
"measure": "smeBids",
"relatedLot": "3"
},
{
"id": "3",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "1"
},
{
"id": "8",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "2"
},
{
"id": "13",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "5"
},
{
"id": "18",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "6"
},
{
"id": "23",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "7"
},
{
"id": "28",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "8"
},
{
"id": "33",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "9"
},
{
"id": "38",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "10"
},
{
"id": "43",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "11"
},
{
"id": "48",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "12"
},
{
"id": "53",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "14"
},
{
"id": "58",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "16"
},
{
"id": "63",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "13"
},
{
"id": "68",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "15"
},
{
"id": "73",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "3"
},
{
"id": "4",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "1"
},
{
"id": "9",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "2"
},
{
"id": "14",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "5"
},
{
"id": "19",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "6"
},
{
"id": "24",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "7"
},
{
"id": "29",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "8"
},
{
"id": "34",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "9"
},
{
"id": "39",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "10"
},
{
"id": "44",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "11"
},
{
"id": "49",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "12"
},
{
"id": "54",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "14"
},
{
"id": "59",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "16"
},
{
"id": "64",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "13"
},
{
"id": "69",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "15"
},
{
"id": "74",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "3"
},
{
"id": "5",
"value": 7,
"measure": "electronicBids",
"relatedLot": "1"
},
{
"id": "10",
"value": 9,
"measure": "electronicBids",
"relatedLot": "2"
},
{
"id": "15",
"value": 8,
"measure": "electronicBids",
"relatedLot": "5"
},
{
"id": "20",
"value": 3,
"measure": "electronicBids",
"relatedLot": "6"
},
{
"id": "25",
"value": 4,
"measure": "electronicBids",
"relatedLot": "7"
},
{
"id": "30",
"value": 5,
"measure": "electronicBids",
"relatedLot": "8"
},
{
"id": "35",
"value": 3,
"measure": "electronicBids",
"relatedLot": "9"
},
{
"id": "40",
"value": 5,
"measure": "electronicBids",
"relatedLot": "10"
},
{
"id": "45",
"value": 4,
"measure": "electronicBids",
"relatedLot": "11"
},
{
"id": "50",
"value": 3,
"measure": "electronicBids",
"relatedLot": "12"
},
{
"id": "55",
"value": 5,
"measure": "electronicBids",
"relatedLot": "14"
},
{
"id": "60",
"value": 7,
"measure": "electronicBids",
"relatedLot": "16"
},
{
"id": "65",
"value": 5,
"measure": "electronicBids",
"relatedLot": "13"
},
{
"id": "70",
"value": 9,
"measure": "electronicBids",
"relatedLot": "15"
},
{
"id": "75",
"value": 6,
"measure": "electronicBids",
"relatedLot": "3"
}
]
},
"date": "2021-01-05T15:16:04Z",
"ocid": "ocds-h6vhtk-0287ce",
"buyer": {
"id": "GB-FTS-346",
"name": "The City of Edinburgh Council"
},
"links": [
{
"rel": "prev",
"href": "https://ted.europa.eu/udl?uri=TED:NOTICE:161372-2019:TEXT:EN:HTML"
}
],
"awards": [
{
"id": "000136-2021-1",
"title": "Electrical Works Supply and/or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-347",
"name": "Maclin Electric Ltd"
},
{
"id": "GB-FTS-358",
"name": "Nicholson Bros (Electrical Contractors) Ltd"
},
{
"id": "GB-FTS-359",
"name": "G D Chalmers Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-351",
"name": "T B Mackay Energy Services Ltd"
},
{
"id": "GB-FTS-352",
"name": "Easy Heat Systems Ltd"
},
{
"id": "GB-FTS-360",
"name": "OpenView Security Solutions Ltd"
},
{
"id": "GB-FTS-361",
"name": "Belac Group Limited"
}
],
"relatedLots": [
"1"
]
},
{
"id": "000136-2021-2",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works Less than 500,000 GBP.",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-348",
"name": "Morris & Spottiswood"
},
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited"
},
{
"id": "GB-FTS-362",
"name": "Apex Developments Ltd"
},
{
"id": "GB-FTS-363",
"name": "Concrete Repairs ltd"
},
{
"id": "GB-FTS-357",
"name": "Ailsa Building Contractors Ltd"
},
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-364",
"name": "Insulated Render Systems (Scotland) Limited"
},
{
"id": "GB-FTS-365",
"name": "Bell Decorating Group Limited"
}
],
"relatedLots": [
"2"
]
},
{
"id": "000136-2021-3",
"title": "Kitchen and Bathroom, Supply and/or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-365",
"name": "Bell Decorating Group Limited"
},
{
"id": "GB-FTS-366",
"name": "Mears Group"
},
{
"id": "GB-FTS-367",
"name": "Novus Property Solutions Ltd"
},
{
"id": "GB-FTS-361",
"name": "Belac Group Limited"
},
{
"id": "GB-FTS-368",
"name": "McTear Contracts Ltd."
}
],
"relatedLots": [
"5"
]
},
{
"id": "000136-2021-4",
"title": "Lift Replacement, Refurbishment and Upgrading Works - Supply and/or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-350",
"name": "Caltech Lifts Ltd"
},
{
"id": "GB-FTS-369",
"name": "Consult Lift Services Ltd"
},
{
"id": "GB-FTS-370",
"name": "Omega Lift Services LTD"
}
],
"relatedLots": [
"6"
]
},
{
"id": "000136-2021-5",
"title": "Mechanical Installations and Upgrading Works - Supply and/or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-351",
"name": "T B Mackay Energy Services Ltd"
},
{
"id": "GB-FTS-352",
"name": "Easy Heat Systems Ltd"
},
{
"id": "GB-FTS-371",
"name": "JGM - John G Mackintosh"
}
],
"relatedLots": [
"7"
]
},
{
"id": "000136-2021-6",
"title": "Domestic Gas and Plumbing Installations, Supply and or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-352",
"name": "Easy Heat Systems Ltd"
},
{
"id": "GB-FTS-372",
"name": "Everwarm Ltd"
},
{
"id": "GB-FTS-373",
"name": "Gas Call Services Ltd"
},
{
"id": "GB-FTS-374",
"name": "Dalex Systems"
},
{
"id": "GB-FTS-375",
"name": "L&D Plumbing & Tiling Services Ltd"
}
],
"relatedLots": [
"8"
]
},
{
"id": "000136-2021-7",
"title": "Security - Door and Alarm Systems",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-353",
"name": "Eden Group"
},
{
"id": "GB-FTS-360",
"name": "OpenView Security Solutions Ltd"
},
{
"id": "GB-FTS-376",
"name": "North SV"
}
],
"relatedLots": [
"9"
]
},
{
"id": "000136-2021-8",
"title": "Painting, Decorating and Associated Preparation Works Internal and External",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-365",
"name": "Bell Decorating Group Limited"
},
{
"id": "GB-FTS-367",
"name": "Novus Property Solutions Ltd"
},
{
"id": "GB-FTS-377",
"name": "Trident Maintenance Services"
},
{
"id": "GB-FTS-378",
"name": "Mitie Property Services (UK) Ltd"
}
],
"relatedLots": [
"10"
]
},
{
"id": "000136-2021-9",
"title": "Adaptations - Ramp Installations",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited"
},
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-351",
"name": "T B Mackay Energy Services Ltd"
}
],
"relatedLots": [
"11"
]
},
{
"id": "000136-2021-10",
"title": "Lead Replacement, Distribution Pipework Removal and Replacement",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-361",
"name": "Belac Group Limited"
}
],
"relatedLots": [
"12"
]
},
{
"id": "000136-2021-11",
"title": "Demolition City Wide - less than 250k GBP",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-356",
"name": "JCJ Demolition and Construction Ltd"
},
{
"id": "GB-FTS-379",
"name": "Dem-Master Demolition Ltd"
},
{
"id": "GB-FTS-380",
"name": "Coleman & Company Limited"
},
{
"id": "GB-FTS-381",
"name": "Central Demolition Ltd"
},
{
"id": "GB-FTS-382",
"name": "Daltons Demolitions Limited"
}
],
"relatedLots": [
"14"
]
},
{
"id": "000136-2021-12",
"title": "External Works – Neighbourhood Environmental Projects (NEPs)",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited"
},
{
"id": "GB-FTS-383",
"name": "P1 Solutions Ltd"
},
{
"id": "GB-FTS-384",
"name": "Glendale Grounds Management Ltd"
},
{
"id": "GB-FTS-385",
"name": "Mackenzie Construction Ltd"
},
{
"id": "GB-FTS-386",
"name": "J Sives Surfacing Ltd"
},
{
"id": "GB-FTS-387",
"name": "Thomas Menzies (Builders) Ltd"
},
{
"id": "GB-FTS-388",
"name": "Hillhouse Quarry Group Ltd T/A MacASPHALT"
}
],
"relatedLots": [
"16"
]
},
{
"id": "000136-2021-13",
"title": "Demolition City Wide - less than 250k GBP",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-356",
"name": "JCJ Demolition and Construction Ltd"
},
{
"id": "GB-FTS-379",
"name": "Dem-Master Demolition Ltd"
},
{
"id": "GB-FTS-380",
"name": "Coleman & Company Limited"
},
{
"id": "GB-FTS-381",
"name": "Central Demolition Ltd"
},
{
"id": "GB-FTS-382",
"name": "Daltons Demolitions Limited"
}
],
"relatedLots": [
"13"
]
},
{
"id": "000136-2021-14",
"title": "Energy Efficiency",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-357",
"name": "Ailsa Building Contractors Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-364",
"name": "Insulated Render Systems (Scotland) Limited"
},
{
"id": "GB-FTS-389",
"name": "A.C. Whyte & Co. Ltd."
},
{
"id": "GB-FTS-372",
"name": "Everwarm Ltd"
},
{
"id": "GB-FTS-390",
"name": "Procast Building Contractors Ltd"
},
{
"id": "GB-FTS-391",
"name": "MP Group UK Limited"
},
{
"id": "GB-FTS-392",
"name": "SERS Energy Solutions (Scotland) Ltd"
}
],
"relatedLots": [
"15"
]
},
{
"id": "000136-2021-15",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works greater than 500,000 GBP",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-348",
"name": "Morris & Spottiswood"
},
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited"
},
{
"id": "GB-FTS-363",
"name": "Concrete Repairs ltd"
},
{
"id": "GB-FTS-357",
"name": "Ailsa Building Contractors Ltd"
},
{
"id": "GB-FTS-364",
"name": "Insulated Render Systems (Scotland) Limited"
},
{
"id": "GB-FTS-389",
"name": "A.C. Whyte & Co. Ltd."
}
],
"relatedLots": [
"3"
]
}
],
"tender": {
"id": "ocds-h6vhtk-0287ce",
"lots": [
{
"id": "3",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works greater than 500,000 GBP",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nRoofing:\nPlumbing/Drainage:\nAdaptations:\nPest control:\nStructures:\nOther adhoc works\nCondition Surveys\nSustainable Energy:\nProfessional Services:\nTrades: Not limited to\nPlastering - All forms of traditional and non-traditional plastering, including localised repairs and full room fit out replacement\nJoinery - All forms of joinery as required\nElectrician – minor and major electrical works\nPlease refer to Schedule 1 Lot 3 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "2",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works Less than 500,000 GBP.",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nRoofing:\nPlumbing/Drainage:\nAdaptations:\nPest control:\nStructures:\nOther adhoc works\nCondition Surveys\nSustainable Energy:\nProfessional Services:\nTrades: Not limited to\nPlastering - All forms of traditional and non-traditional plastering, including localised repairs and full room fit out replacement\nJoinery - All forms of joinery as required\nElectrician – minor and major electrical works\nPlease refer to Schedule 1 Lot 2 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "5",
"title": "Kitchen and Bathroom, Supply and/or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nSupply and/or install Kitchens and bathrooms including design\nOther adhoc works\nCondition Surveys\nProfessional Services:\nTrades: Not limited to\nJoinery - All forms of joinery as required\nElectrician\nPlumber\nGas Engineer\nPlasterer\nPlease refer to Schedule 1 Lot 5 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "16",
"title": "External Works – Neighbourhood Environmental Projects (NEPs)",
"status": "cancelled",
"hasOptions": false,
"description": "Works consist of a series of undefined, external refurbishment and upgrading projects on Council land.\nIt is anticipated that most projects will be with neighbourhoods but could be anywhere in the Councils portfolio of land.\nWorks will be carried out in consultation with the client(CEC), community groups, owners, tenants, and members of the public, and the contractor may on occasion be required to attend briefings with council staff/local community groups/elected members.\nWork will consist of the following but not limited to:\nRemoval of debris in line with environmental legislation.\nSite security and safety measures.\nLiaising with appropriate utility companies to arrange appropriate licenses, permit and agreement to carry out works. – where possible specifics will be set out in mini tender documents. All discussions surrounding utilities unknown until works began, must be led by the Contractor.\nEnsure traffic management systems, including road closures are in place and agreed with Locality prior to commencement of works, where applicable.\nEnsure appropriate signage is in place to inform residents of works, safety and start and end dates of works.\nHot works permits for all appropriate works.\nTemporary work solutions, shoring, propping, protection.\nSite clearance, cleaning, reinstatement to original state/condition.\nRepair/removal/replacement/installation works relating to landscaping, fencing, drainage, earthworks, geotechnical, piling and underpinning.\nRepair/removal/replacement/installation works relating to play areas and play/exercise equipment etc.\nRepair/removal/replacement/installation works relating to concrete structures.\nRepair/removal/replacement of roads/paths and the like\nUndertaking and provision of testing/reporting.\nInstallation of structural supports/repairs/strengthening as directed.\nSite investigations and reports where required.\nWaste removal and site clear up.\nOther ad hoc and associated works.\nPlease refer to Schedule 1 Lot 16 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "8",
"title": "Domestic Gas and Plumbing Installations, Supply and or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nGenerally, the work will consist of - Supply and/or Install replacement or upgrading of:\nGas Boiler Replacements (maybe issued by CEC)\nRadiator Replacements\nHeating and distribution Pipework.\nHot Water Storage Cylinder Replacements\nFull Central Heating System Replacements and upgrades\nControls Upgrades and Replacements.\nDomestic components related to renewable heating technologies.\nAttendance to Defects and Failures (Generally within defects period)\nDomestic Hot Water (DHW), Domestic Cold Water (DCW) and Mains Cold Water (MCW) distribution pipework, storage systems, pumps and control systems and drainage systems.\nPlease refer to Schedule 1 Lot 8 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "6",
"title": "Lift Replacement, Refurbishment and Upgrading Works - Supply and/or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nDesign, Supply and or Installation of Refurbishments, Upgrades or New Electronic Passenger Lift Car/Cars (including Machine, Controllers & Drive, Overspeed Governor, Lift Car & Sling, Landing Entrance including Push Buttons & Indicators, sundries. This may or may not include Guides & Counterweights) within existing buildings. Including, delivery (including off-loading), dismantling and removal of the equivalent existing equipment, and all necessary and associated skills and trades.\nTesting and identification of all beams, handling and lifting equipment.\nThe dismantling and safe removal and disposal of the equivalent existing equipment.\nPlease refer to Schedule 1 Lot 6 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "7",
"title": "Mechanical Installations and Upgrading Works - Supply and/or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic and commercial Properties, although there may be a need to carry out works in mixed tenure and other building types as the need arises.\nThe remit of this contract will require contractors to replace commercial installations which may include some forms of electrical control equipment (BMS)\nGenerally, the work will consist of the replacement or upgrading of:\nCommercial Heating/Hot Water Systems:\nUpgrading/replacement or maintenance of commercial heating/hot water systems within commercial properties and domestic properties including multi storey blocks; including all associated boilers (all fuels), plant & equipment, calorifiers & storage tanks, pipework, pumps & valves, heat emitters, trace heating and management systems etc.\nAOV Systems (Automatic Opening Vent):\nUpgrading/replacement or maintenance of AOV systems within commercial properties and multi storey blocks, including all associated control panels, cabling, components, smoke detectors, control systems and routine testing and maintenance as required etc.\nVentilation Systems:\nUpgrading/replacement or maintenance of commercial ventilation systems within commercial properties and domestic properties including multi storey blocks; including all associated plant & equipment, pipework, pumps & valves, fans, heating elements, HVAC systems and management systems etc.\nFire Suppression & Sprinkler Systems:\nUpgrading/replacement or maintenance of fire suppression & sprinkler systems within\ncommercial properties and domestic properties including multi storey blocks; including all associated plant & equipment, pipework, pumps & valves, dry risers and management systems etc.\nGenerators:\nUpgrading/replacement or maintenance of generators / mobile generators for commercial properties and domestic properties including multi storey blocks; including all associated plant, equipment and management/control systems etc.\nPlease refer to Schedule 1 Lot 7 for further information on the scope of this Lot\nThis lot is broken in to sub lots\n1.1 Commercial Heating/Hot Water Systems\n1.2 AOV Systems (Automatic Opening Vent)\n1.3 Ventilation Systems\n1.4 Fire Suppression & Sprinkler Systems\n1.5 Generators",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "9",
"title": "Security - Door and Alarm Systems",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nGenerally, the work will consist of - Supply and/or Install replacement or upgrading of:\nDoor Entry:\nInstallation of an electronically controlled door entry system to be activated from handsets within individual flats.\nCCTV Systems:\nInstallation of CCTV systems, including the removal, disposal and replacement or repair of existing systems.\nWorks shall include the removal, disposal and replacement or repair of existing systems\nAll existing electronic infrastructure shall be checked and upgraded as appropriate.\nWarden Call Systems:\nInstallation of Warden Call Systems, including the removal, disposal and replacement or repair of existing systems. All existing electronic infrastructure shall be checked and upgraded as appropriate.\nInstallation of individual bespoke systems for particularly vulnerable or disabled tenants.\nInstallations of grouped systems, combined warden call systems and dispersed alarms.\nCommunal TV / Satellite Systems (Passive & Active):\nInstallation of communal TV, Satellite and Integrated Reception Systems (IRS) systems, including the repair or removal, disposal and replacement of existing systems.\nAll existing electronic infrastructure shall be checked and upgraded as appropriate.\nPlease refer to Schedule 1 Lot 9 for further information on the scope of this Lot\nThis lot is broken in to sub lots\n1.1 Secure Door Entry Systems\n1.2 CCTV Systems\n1.3 Warden Call Systems\n1.4 Communal TV/Satellite/IRS Systems",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "15",
"title": "Energy Efficiency",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nInternal wall insulation:\nDraught proofing of doors and windows\nInstalling under floor insulation\nInstalling insulated flat roof system Installing insulated plasterboard to internal walls and ceilings\nExternal wall insulation:\nApplying appropriate insulation material to exposed concrete areas, such as garages and exposed under-croft ceiling spaces\nDraught proofing of doors and windows\nInstalling External Wall Insulation systems\nLoft insulation:\nInsulating of pipe work in lofts and under floors\nInstalling roof vents in loft spaces\nInstalling or topping up loft insulation\nRelaying of damaged/missing loft insulation\nCavity Wall Insulation:\nCarrying out cavity wall insulation installation or extract/refill of defective insulation\nSustainable Energy:\nInstalling Solar PV or Solar Hot Water systems\nProvide the appropriately qualified and experienced trades for enabling works that include, electricians, joiners, gas engineers, plumbers and painters\nEPC Certification (Energy Performance Certificate):\nVisiting tenants in their homes and carrying out energy surveys which also identify any other defects with the property that may impact on the installation of any insulation measures\nProducing an ‘Energy Survey Report’ for CEC identifying any insulation requirements that includes both U-value and Dew Point calculations\nProducing SAP reports or Energy Performance Certificate (EPC) lodged with the Scottish EPC register before and/or after installation of the measure as instructed\nCarry out monitoring of the effectiveness of installed measures in tenant’s property\nPlease refer to Schedule 1 Lot 15 for further information on the scope of this Lot\nThis lot is broken in to sub lots\n1.1 Internal Wall Insulation\n1.2 External wall insulation\n1.3 Loft Insulation\n1.4 Cavity Wall Insulation\n1.5 Sustainable Energy\n1.6 Energy Performance Certification",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "10",
"title": "Painting, Decorating and Associated Preparation Works Internal and External",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nWorks could include: but not limited to\nPreparation and Decoration to External Render/Bick/Block Walls\nPreparation and Decoration to Common Stairs Walls & Ceilings (fire retardant and anti-graffiti systems may be required)\nPreparation and Decoration to External Fascia’s, Bargeboards, eaves etc. Preparation and Decoration to High Rise Drying Areas\nPlease refer to Schedule 1 Lot 10 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "14",
"title": "Demolition City Wide - less than 250k GBP",
"status": "cancelled",
"hasOptions": false,
"description": "The works shall include safe and controlled and emergency demolition of commercial and domestic Buildings, including demolition by explosives of non-traditional and traditional high and low rise structures within the domestic and non-domestic sectors and removal of all debris arising.\nSafe removal and excavation of foundations, substructure fill material including contaminated materials, underground services and removal of all debris arising.\nSite reinstatement shall be required including bringing to site imported fill material and/or selected crush material arising from the demolitions together with top soiling and seeding and the provision of long and short term fencing of completed sites including signage.\nOn occasions contractors will be expected to respond to a requirement for a structure to be demolished at short notice.\nCo-operate with all power/gas/IT/utility providers, external consultants, police/emergency services, all other council and private ‘neighbours’\nCo-operate with city archaeologist if required\nShall act as Principal Contractor (CDMC) and produce all relevant forms/information.\nCompliance with H&S, Asbestos removal\nContractors shall be a licensed to remove asbestos and be members of a recognised registration body such as NFDC for the duration of the framework contract.\nAll other adhoc associated works.\nPlease refer to Schedule 1 Lot 14 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "11",
"title": "Adaptations - Ramp Installations",
"status": "cancelled",
"hasOptions": false,
"description": "The successful Contractor/s will be required to supply and/or install permeant or temporary ramps at predominately domestic properties throughout the Councils estate, as and when identified by the Council representatives.\nIn addition, there may be a requirement to dismantle and or reinstall existing equipment at new locations, as and when identified by the Council.\nPermanent and temporary ramps may be fabricated in metal or constructed in\nbrick/block and concrete.\nAll ramps must comply with all regulations, be constructed to the correct gradient for the available distance, have all the necessary platforms/landings/steps and handrails as required, be non-slip etc., additional steps/plats: to be constructed with brick/block and concrete, any additional handrails etc. which may be installed at existing or new steps\nAll the above to allow access to dwellings/buildings, all in compliance with Disability Discrimination Act (DDA) Regulations.\nAn element of contractor’s design will be required.\nAll other adhoc works\nPlease refer to Schedule 1 Lot 11 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "13",
"title": "Demolition City Wide - less than 250k GBP",
"status": "cancelled",
"hasOptions": false,
"description": "The works shall include safe and controlled and emergency demolition of commercial and domestic Buildings, including demolition by explosives of non-traditional and traditional high and low rise structures within the domestic and non-domestic sectors and removal of all debris arising.\nSafe removal and excavation of foundations, substructure fill material including contaminated materials, underground services and removal of all debris arising.\nSite reinstatement shall be required including bringing to site imported fill material and/or selected crush material arising from the demolitions together with top soiling and seeding and the provision of long and short term fencing of completed sites including signage.\nOn occasions contractors will be expected to respond to a requirement for a structure to be demolished at short notice.\nCo-operate with all power/gas/IT/utility providers, external consultants, police/emergency services, all other council and private ‘neighbours’\nCo-operate with city archaeologist if required\nShall act as Principal Contractor (CDMC) and produce all relevant forms/information.\nCompliance with H&S, Asbestos removal\nContractors shall be a licensed to remove asbestos and be members of a recognised registration body such as NFDC for the duration of the framework contract.\nAll other adhoc associated works.\nPlease refer to Schedule 1 Lot 13 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "12",
"title": "Lead Replacement, Distribution Pipework Removal and Replacement",
"status": "cancelled",
"hasOptions": false,
"description": "Works will be carried out to private supply pipework located within and connected to Mains Distribution pipe work in and around traditional and non-traditional high and low rise domestic and commercial properties.\nThe work will include, but not be limited to;\nThe removal & safe disposal of all existing lead pipework\nThe replacement of the lead pipework with new copper pipework to hot and cold supply systems including all valves/accessories and sundries required,\nFlushing, filling & commissioning pipes/cisterns and all associated testing and certification,\nEarthing and all associated testing & certification.\nPipework insulation,\nNew cisterns for potable water as required,\nBuilder work in connection with, hot and cold supply pipes,\nUnderground plastic/clay pipework including all tapes/bedding/surrounds and haunching, making good roadways/pedestrian pavements,\nPlease refer to Schedule 1 Lot 12 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "1",
"title": "Electrical Works Supply and/or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nBrief scope\nElectrical refit/rewire\nElectric Heating\nFire/Smoke Detection\nEmergency Lighting Systems\nAdhoc works\nthis lot is broken in to sub lots",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
}
],
"items": [
{
"id": "3",
"relatedLot": "3",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "44220000",
"scheme": "CPV",
"description": "Builders' joinery"
},
{
"id": "45420000",
"scheme": "CPV",
"description": "Joinery and carpentry installation work"
},
{
"id": "45421000",
"scheme": "CPV",
"description": "Joinery work"
},
{
"id": "45421140",
"scheme": "CPV",
"description": "Installation of metal joinery except doors and windows"
},
{
"id": "45421150",
"scheme": "CPV",
"description": "Non-metal joinery installation work"
},
{
"id": "45311000",
"scheme": "CPV",
"description": "Electrical wiring and fitting work"
},
{
"id": "45311100",
"scheme": "CPV",
"description": "Electrical wiring work"
},
{
"id": "45311200",
"scheme": "CPV",
"description": "Electrical fitting work"
},
{
"id": "45315100",
"scheme": "CPV",
"description": "Electrical engineering installation works"
},
{
"id": "45317000",
"scheme": "CPV",
"description": "Other electrical installation work"
},
{
"id": "45310000",
"scheme": "CPV",
"description": "Electrical installation work"
},
{
"id": "45315000",
"scheme": "CPV",
"description": "Electrical installation work of heating and other electrical building-equipment"
},
{
"id": "45421100",
"scheme": "CPV",
"description": "Installation of doors and windows and related components"
},
{
"id": "45421110",
"scheme": "CPV",
"description": "Installation of door and window frames"
},
{
"id": "45421112",
"scheme": "CPV",
"description": "Installation of window frames"
},
{
"id": "45421132",
"scheme": "CPV",
"description": "Installation of windows"
},
{
"id": "45421151",
"scheme": "CPV",
"description": "Installation of fitted kitchens"
},
{
"id": "45211310",
"scheme": "CPV",
"description": "Bathrooms construction work"
},
{
"id": "45211000",
"scheme": "CPV",
"description": "Construction work for multi-dwelling buildings and individual houses"
},
{
"id": "51120000",
"scheme": "CPV",
"description": "Installation services of mechanical equipment"
},
{
"id": "51111200",
"scheme": "CPV",
"description": "Installation services of generators"
},
{
"id": "51100000",
"scheme": "CPV",
"description": "Installation services of electrical and mechanical equipment"
},
{
"id": "45350000",
"scheme": "CPV",
"description": "Mechanical installations"
},
{
"id": "45351000",
"scheme": "CPV",
"description": "Mechanical engineering installation works"
},
{
"id": "71314000",
"scheme": "CPV",
"description": "Energy and related services"
},
{
"id": "45442100",
"scheme": "CPV",
"description": "Painting work"
},
{
"id": "45442110",
"scheme": "CPV",
"description": "Painting work of buildings"
},
{
"id": "45442120",
"scheme": "CPV",
"description": "Painting and protective-coating work of structures"
},
{
"id": "44230000",
"scheme": "CPV",
"description": "Builders' carpentry"
},
{
"id": "45443000",
"scheme": "CPV",
"description": "Facade work"
},
{
"id": "45410000",
"scheme": "CPV",
"description": "Plastering work"
}
]
},
{
"id": "2",
"relatedLot": "2",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45260000",
"scheme": "CPV",
"description": "Roof works and other special trade construction works"
},
{
"id": "45262000",
"scheme": "CPV",
"description": "Special trade construction works other than roof works"
},
{
"id": "44220000",
"scheme": "CPV",
"description": "Builders' joinery"
},
{
"id": "45420000",
"scheme": "CPV",
"description": "Joinery and carpentry installation work"
},
{
"id": "45421150",
"scheme": "CPV",
"description": "Non-metal joinery installation work"
},
{
"id": "45421140",
"scheme": "CPV",
"description": "Installation of metal joinery except doors and windows"
},
{
"id": "09300000",
"scheme": "CPV",
"description": "Electricity, heating, solar and nuclear energy"
},
{
"id": "45311000",
"scheme": "CPV",
"description": "Electrical wiring and fitting work"
},
{
"id": "45311100",
"scheme": "CPV",
"description": "Electrical wiring work"
},
{
"id": "45311200",
"scheme": "CPV",
"description": "Electrical fitting work"
},
{
"id": "45315100",
"scheme": "CPV",
"description": "Electrical engineering installation works"
},
{
"id": "45317000",
"scheme": "CPV",
"description": "Other electrical installation work"
},
{
"id": "45310000",
"scheme": "CPV",
"description": "Electrical installation work"
},
{
"id": "45315000",
"scheme": "CPV",
"description": "Electrical installation work of heating and other electrical building-equipment"
},
{
"id": "45421100",
"scheme": "CPV",
"description": "Installation of doors and windows and related components"
},
{
"id": "45421110",
"scheme": "CPV",
"description": "Installation of door and window frames"
},
{
"id": "45421112",
"scheme": "CPV",
"description": "Installation of window frames"
},
{
"id": "45421130",
"scheme": "CPV",
"description": "Installation of doors and windows"
},
{
"id": "45421132",
"scheme": "CPV",
"description": "Installation of windows"
},
{
"id": "45421151",
"scheme": "CPV",
"description": "Installation of fitted kitchens"
},
{
"id": "45211310",
"scheme": "CPV",
"description": "Bathrooms construction work"
},
{
"id": "45211000",
"scheme": "CPV",
"description": "Construction work for multi-dwelling buildings and individual houses"
},
{
"id": "51120000",
"scheme": "CPV",
"description": "Installation services of mechanical equipment"
},
{
"id": "51111200",
"scheme": "CPV",
"description": "Installation services of generators"
},
{
"id": "51100000",
"scheme": "CPV",
"description": "Installation services of electrical and mechanical equipment"
},
{
"id": "45350000",
"scheme": "CPV",
"description": "Mechanical installations"
},
{
"id": "45351000",
"scheme": "CPV",
"description": "Mechanical engineering installation works"
},
{
"id": "71314000",
"scheme": "CPV",
"description": "Energy and related services"
},
{
"id": "45442100",
"scheme": "CPV",
"description": "Painting work"
},
{
"id": "45442110",
"scheme": "CPV",
"description": "Painting work of buildings"
},
{
"id": "45442120",
"scheme": "CPV",
"description": "Painting and protective-coating work of structures"
},
{
"id": "44230000",
"scheme": "CPV",
"description": "Builders' carpentry"
},
{
"id": "45443000",
"scheme": "CPV",
"description": "Facade work"
},
{
"id": "45410000",
"scheme": "CPV",
"description": "Plastering work"
}
]
},
{
"id": "5",
"relatedLot": "5",
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45211310",
"scheme": "CPV",
"description": "Bathrooms construction work"
},
{
"id": "45421151",
"scheme": "CPV",
"description": "Installation of fitted kitchens"
},
{
"id": "44410000",
"scheme": "CPV",
"description": "Articles for the bathroom and kitchen"
},
{
"id": "39141400",
"scheme": "CPV",
"description": "Fitted kitchens"
}
]
},
{
"id": "16",
"relatedLot": "16",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45111240",
"scheme": "CPV",
"description": "Ground-drainage work"
},
{
"id": "45112720",
"scheme": "CPV",
"description": "Landscaping work for sports grounds and recreational areas"
},
{
"id": "45112723",
"scheme": "CPV",
"description": "Landscaping work for playgrounds"
},
{
"id": "45212221",
"scheme": "CPV",
"description": "Construction work in connection with structures for sports ground"
},
{
"id": "71421000",
"scheme": "CPV",
"description": "Landscape gardening services"
},
{
"id": "71400000",
"scheme": "CPV",
"description": "Urban planning and landscape architectural services"
}
]
},
{
"id": "8",
"relatedLot": "8",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "39715000",
"scheme": "CPV",
"description": "Water heaters and heating for buildings; plumbing equipment"
},
{
"id": "39715200",
"scheme": "CPV",
"description": "Heating equipment"
},
{
"id": "42160000",
"scheme": "CPV",
"description": "Boiler installations"
},
{
"id": "44620000",
"scheme": "CPV",
"description": "Central-heating radiators and boilers and parts"
},
{
"id": "44621000",
"scheme": "CPV",
"description": "Radiators and boilers"
},
{
"id": "44621200",
"scheme": "CPV",
"description": "Boilers"
},
{
"id": "44621210",
"scheme": "CPV",
"description": "Water boilers"
},
{
"id": "42161000",
"scheme": "CPV",
"description": "Hot-water boilers"
},
{
"id": "39721410",
"scheme": "CPV",
"description": "Gas appliances"
}
]
},
{
"id": "6",
"relatedLot": "6",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45313100",
"scheme": "CPV",
"description": "Lift installation work"
},
{
"id": "45313000",
"scheme": "CPV",
"description": "Lift and escalator installation work"
},
{
"id": "51511100",
"scheme": "CPV",
"description": "Installation services of lifting equipment"
},
{
"id": "42416100",
"scheme": "CPV",
"description": "Lifts"
},
{
"id": "42416120",
"scheme": "CPV",
"description": "Goods lifts"
},
{
"id": "42416130",
"scheme": "CPV",
"description": "Mechanical lifts"
},
{
"id": "50750000",
"scheme": "CPV",
"description": "Lift-maintenance services"
}
]
},
{
"id": "7",
"relatedLot": "7",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45310000",
"scheme": "CPV",
"description": "Electrical installation work"
},
{
"id": "31100000",
"scheme": "CPV",
"description": "Electric motors, generators and transformers"
},
{
"id": "31120000",
"scheme": "CPV",
"description": "Generators"
},
{
"id": "31122000",
"scheme": "CPV",
"description": "Generator units"
},
{
"id": "31127000",
"scheme": "CPV",
"description": "Emergency generator"
},
{
"id": "39563530",
"scheme": "CPV",
"description": "Ventilation ducting"
},
{
"id": "42500000",
"scheme": "CPV",
"description": "Cooling and ventilation equipment"
},
{
"id": "42520000",
"scheme": "CPV",
"description": "Ventilation equipment"
},
{
"id": "45331000",
"scheme": "CPV",
"description": "Heating, ventilation and air-conditioning installation work"
},
{
"id": "45331200",
"scheme": "CPV",
"description": "Ventilation and air-conditioning installation work"
},
{
"id": "45331211",
"scheme": "CPV",
"description": "Outdoor ventilation installation work"
},
{
"id": "71315410",
"scheme": "CPV",
"description": "Inspection of ventilation system"
},
{
"id": "35111500",
"scheme": "CPV",
"description": "Fire suppression system"
},
{
"id": "35111510",
"scheme": "CPV",
"description": "Fire suppression hand tools"
},
{
"id": "35111520",
"scheme": "CPV",
"description": "Fire suppression foam or similar compounds"
},
{
"id": "09321000",
"scheme": "CPV",
"description": "Hot water"
},
{
"id": "45311200",
"scheme": "CPV",
"description": "Electrical fitting work"
},
{
"id": "45311100",
"scheme": "CPV",
"description": "Electrical wiring work"
},
{
"id": "45311000",
"scheme": "CPV",
"description": "Electrical wiring and fitting work"
},
{
"id": "44621111",
"scheme": "CPV",
"description": "Non-electrically-heated central-heating radiators"
},
{
"id": "44111530",
"scheme": "CPV",
"description": "Electrical insulating fittings"
},
{
"id": "44111511",
"scheme": "CPV",
"description": "Electrical insulators"
},
{
"id": "45315000",
"scheme": "CPV",
"description": "Electrical installation work of heating and other electrical building-equipment"
},
{
"id": "45315100",
"scheme": "CPV",
"description": "Electrical engineering installation works"
},
{
"id": "45317100",
"scheme": "CPV",
"description": "Electrical installation work of pumping equipment"
},
{
"id": "45317200",
"scheme": "CPV",
"description": "Electrical installation work of transformers"
},
{
"id": "71334000",
"scheme": "CPV",
"description": "Mechanical and electrical engineering services"
},
{
"id": "71323100",
"scheme": "CPV",
"description": "Electrical power systems design services"
},
{
"id": "51100000",
"scheme": "CPV",
"description": "Installation services of electrical and mechanical equipment"
}
]
},
{
"id": "9",
"relatedLot": "9",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "35125300",
"scheme": "CPV",
"description": "Security cameras"
},
{
"id": "35121300",
"scheme": "CPV",
"description": "Security fittings"
},
{
"id": "35121000",
"scheme": "CPV",
"description": "Security equipment"
},
{
"id": "35120000",
"scheme": "CPV",
"description": "Surveillance and security systems and devices"
},
{
"id": "35100000",
"scheme": "CPV",
"description": "Emergency and security equipment"
},
{
"id": "32324310",
"scheme": "CPV",
"description": "Satellite antennas"
},
{
"id": "34712200",
"scheme": "CPV",
"description": "Satellites"
},
{
"id": "45312000",
"scheme": "CPV",
"description": "Alarm system and antenna installation work"
},
{
"id": "79711000",
"scheme": "CPV",
"description": "Alarm-monitoring services"
},
{
"id": "35121700",
"scheme": "CPV",
"description": "Alarm systems"
}
]
},
{
"id": "15",
"relatedLot": "15",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "09330000",
"scheme": "CPV",
"description": "Solar energy"
},
{
"id": "71314300",
"scheme": "CPV",
"description": "Energy-efficiency consultancy services"
},
{
"id": "45261410",
"scheme": "CPV",
"description": "Roof insulation work"
},
{
"id": "45320000",
"scheme": "CPV",
"description": "Insulation work"
},
{
"id": "45321000",
"scheme": "CPV",
"description": "Thermal insulation work"
}
]
},
{
"id": "10",
"relatedLot": "10",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45442100",
"scheme": "CPV",
"description": "Painting work"
},
{
"id": "45442110",
"scheme": "CPV",
"description": "Painting work of buildings"
},
{
"id": "45442120",
"scheme": "CPV",
"description": "Painting and protective-coating work of structures"
},
{
"id": "45442121",
"scheme": "CPV",
"description": "Painting work of structures"
}
]
},
{
"id": "14",
"relatedLot": "14",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45111100",
"scheme": "CPV",
"description": "Demolition work"
},
{
"id": "45111000",
"scheme": "CPV",
"description": "Demolition, site preparation and clearance work"
},
{
"id": "45110000",
"scheme": "CPV",
"description": "Building demolition and wrecking work and earthmoving work"
}
]
},
{
"id": "11",
"relatedLot": "11",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "34953000",
"scheme": "CPV",
"description": "Access ramps"
}
]
},
{
"id": "13",
"relatedLot": "13",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45110000",
"scheme": "CPV",
"description": "Building demolition and wrecking work and earthmoving work"
},
{
"id": "45111000",
"scheme": "CPV",
"description": "Demolition, site preparation and clearance work"
},
{
"id": "45111100",
"scheme": "CPV",
"description": "Demolition work"
}
]
},
{
"id": "12",
"relatedLot": "12",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "14712000",
"scheme": "CPV",
"description": "Lead"
},
{
"id": "45332200",
"scheme": "CPV",
"description": "Water plumbing work"
},
{
"id": "45332000",
"scheme": "CPV",
"description": "Plumbing and drain-laying work"
},
{
"id": "45111240",
"scheme": "CPV",
"description": "Ground-drainage work"
},
{
"id": "44163110",
"scheme": "CPV",
"description": "Drainage pipes"
},
{
"id": "90660000",
"scheme": "CPV",
"description": "Deleading services"
}
]
},
{
"id": "1",
"relatedLot": "1",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "09300000",
"scheme": "CPV",
"description": "Electricity, heating, solar and nuclear energy"
},
{
"id": "31100000",
"scheme": "CPV",
"description": "Electric motors, generators and transformers"
},
{
"id": "45311000",
"scheme": "CPV",
"description": "Electrical wiring and fitting work"
},
{
"id": "45311100",
"scheme": "CPV",
"description": "Electrical wiring work"
},
{
"id": "38431200",
"scheme": "CPV",
"description": "Smoke-detection apparatus"
},
{
"id": "45310000",
"scheme": "CPV",
"description": "Electrical installation work"
},
{
"id": "45311200",
"scheme": "CPV",
"description": "Electrical fitting work"
},
{
"id": "45315000",
"scheme": "CPV",
"description": "Electrical installation work of heating and other electrical building-equipment"
},
{
"id": "45317000",
"scheme": "CPV",
"description": "Other electrical installation work"
},
{
"id": "45317300",
"scheme": "CPV",
"description": "Electrical installation work of electrical distribution apparatus"
},
{
"id": "71323100",
"scheme": "CPV",
"description": "Electrical power systems design services"
},
{
"id": "51110000",
"scheme": "CPV",
"description": "Installation services of electrical equipment"
}
]
}
],
"title": "Housing Property Capital Works Framework 2019 - 2023",
"status": "complete",
"legalBasis": {
"id": "32014L0024",
"scheme": "CELEX"
},
"techniques": {
"hasFrameworkAgreement": true
},
"description": "Housing Property Capital Works Framework 2019 - 2023\nchanged to 2020 to 2024",
"reviewDetails": "Precise information on deadline(s) for review procedures:\nA tenderer that suffers loss as a result of a breach of duty under the Public Contracts (Scotland) Regulations 2015 may bring proceedings in the Sheriff Court or the Court of Session. The City of Edinburgh Council (the Council) will have a minimum standstill period of 10 days before awarding the contract. The communication of the award decision notice will be sent by fax or e-mail to all tenderers with the standstill period commencing on the next day. If proceedings are started in the Sheriff Court or the Court of Session against the Council in respect of the decision to award the contract within the standstill period then the Council is prevented from awarding the contract. Post contract award the Sheriff Court or the Court of Session may (1) award damages provided proceedings are brought within 3 months from the date when the grounds for the bringing of the proceedings first arose (2) be entitled to issue an ineffectiveness order or impose a financial penalty on the Council. A claim for an ineffectiveness order must be made within 30 days of the Contract Award Notice being published in the OJEU or within 30 days of the date those who expressed an interest in or otherwise bid for the contract were informed of the conclusion of the contract or in any other case within 6 months from the date on which the contract was entered into.",
"classification": {
"id": "45210000",
"scheme": "CPV",
"description": "Building construction work"
},
"procurementMethod": "selective",
"mainProcurementCategory": "works",
"procurementMethodDetails": "Restricted procedure"
},
"parties": [
{
"id": "GB-FTS-346",
"name": "The City of Edinburgh Council",
"roles": [
"buyer"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH8 8BG",
"countryName": "United Kingdom",
"streetAddress": "Waverley Court, 4 East Market Street"
},
"details": {
"url": "http://www.edinburgh.gov.uk",
"buyerProfile": "https://www.publiccontractsscotland.gov.uk/search/Search_AuthProfile.aspx?ID=AA00290",
"classifications": [
{
"id": "REGIONAL_AUTHORITY",
"scheme": "TED_CA_TYPE",
"description": "Regional or local authority"
},
{
"id": "01",
"scheme": "COFOG",
"description": "General public services"
}
]
},
"identifier": {
"legalName": "The City of Edinburgh Council"
},
"contactPoint": {
"email": "lorna.lennen@edinburgh.gov.uk",
"telephone": "+44 1314693922"
}
},
{
"id": "GB-FTS-347",
"name": "Maclin Electric Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Musselburgh",
"postalCode": "EH21 7UL",
"countryName": "United Kingdom",
"streetAddress": "Block 2 Unit 3, Inveresk Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Maclin Electric Ltd"
},
"contactPoint": {
"faxNumber": "+44 1316532589",
"telephone": "+44 1316659991"
}
},
{
"id": "GB-FTS-348",
"name": "Morris & Spottiswood",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G51 3HQ",
"countryName": "United Kingdom",
"streetAddress": "54 Helen Street"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "Morris & Spottiswood"
},
"contactPoint": {
"telephone": "+44 01414254954"
}
},
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM78",
"locality": "Livingston",
"postalCode": "EH54 8AS",
"countryName": "United Kingdom",
"streetAddress": "Caputhall Road, Deans Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Response Building Maintenance Services (Scotland) Ltd"
},
"contactPoint": {
"faxNumber": "+44 01506414181",
"telephone": "+44 01506411555"
}
},
{
"id": "GB-FTS-350",
"name": "Caltech Lifts Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Dundee",
"postalCode": "DD1 3NA",
"countryName": "United Kingdom",
"streetAddress": "Stannergate Road, Broughty Ferry"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Caltech Lifts Ltd"
},
"contactPoint": {
"telephone": "+44 07713981505"
}
},
{
"id": "GB-FTS-351",
"name": "T B Mackay Energy Services Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Edinburgh",
"postalCode": "EH5 1AB",
"countryName": "United Kingdom",
"streetAddress": "219 Granton Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "T B Mackay Energy Services Ltd"
},
"contactPoint": {
"faxNumber": "+44 01315593500",
"telephone": "+44 01315526103"
}
},
{
"id": "GB-FTS-352",
"name": "Easy Heat Systems Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Perth",
"postalCode": "PH1 3TS",
"countryName": "United Kingdom",
"streetAddress": "McDermott House Inveralmond Place, Inveralmond Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Easy Heat Systems Ltd"
},
"contactPoint": {
"telephone": "+44 01738445222"
}
},
{
"id": "GB-FTS-353",
"name": "Eden Group",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Edinburgh",
"postalCode": "EH17 7QJ",
"countryName": "United Kingdom",
"streetAddress": "43 Ellen's Glen Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Eden Group"
},
"contactPoint": {
"telephone": "+44 01316643906"
}
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH14 1UT",
"countryName": "United Kingdom",
"streetAddress": "38 West Gorgie Parks, Edinburgh"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Firstcall Trade Services"
},
"contactPoint": {
"telephone": "+44 01312857150"
}
},
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited",
"roles": [
"supplier"
],
"address": {
"region": "UKM78",
"locality": "Livingston",
"postalCode": "EH54 5DJ",
"countryName": "United Kingdom",
"streetAddress": "Firth Road, Houstoun Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Maxi Construction Limited"
},
"contactPoint": {
"faxNumber": "+44 01506442010",
"telephone": "+44 01506442233"
}
},
{
"id": "GB-FTS-356",
"name": "JCJ Demolition and Construction Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Glasgow",
"postalCode": "G31 5es",
"countryName": "United Kingdom",
"streetAddress": "Nisbet Business Centre, 30 Nisbet St"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "JCJ Demolition and Construction Ltd"
},
"contactPoint": {
"faxNumber": "+44 01415543020",
"telephone": "+44 01415542758"
}
},
{
"id": "GB-FTS-357",
"name": "Ailsa Building Contractors Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Coatbridge",
"postalCode": "ML5 4AU",
"countryName": "United Kingdom",
"streetAddress": "251 Dundyvan Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Ailsa Building Contractors Ltd"
},
"contactPoint": {
"faxNumber": "+44 01236602623",
"telephone": "+44 01236422615"
}
},
{
"id": "GB-FTS-358",
"name": "Nicholson Bros (Electrical Contractors) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH9 1UH",
"countryName": "United Kingdom",
"streetAddress": "6A Grange Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Nicholson Bros (Electrical Contractors) Ltd"
},
"contactPoint": {
"faxNumber": "+44 1316624904",
"telephone": "+44 1316670281"
}
},
{
"id": "GB-FTS-359",
"name": "G D Chalmers Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Paisley",
"postalCode": "PA2 6ES",
"countryName": "United Kingdom",
"streetAddress": "101 Neilston Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "G D Chalmers Ltd"
},
"contactPoint": {
"telephone": "+44 01418896233"
}
},
{
"id": "GB-FTS-360",
"name": "OpenView Security Solutions Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Essex",
"postalCode": "RM7 7PJ",
"countryName": "United Kingdom",
"streetAddress": "OpenView House, Chesham Close, Romford"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "OpenView Security Solutions Ltd"
}
},
{
"id": "GB-FTS-361",
"name": "Belac Group Limited",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Bellshill",
"postalCode": "ML4 3PU",
"countryName": "United Kingdom",
"streetAddress": "Unit 3.4, 17 Starling Way, Western Campus"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Belac Group Limited"
},
"contactPoint": {
"telephone": "+44 1414590010"
}
},
{
"id": "GB-FTS-362",
"name": "Apex Developments Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Edinburgh",
"postalCode": "EH3 6LP",
"countryName": "United Kingdom",
"streetAddress": "8c Northumberland Street South East Lane"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Apex Developments Ltd"
},
"contactPoint": {
"telephone": "+44 01313164747"
}
},
{
"id": "GB-FTS-363",
"name": "Concrete Repairs ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM76",
"locality": "Falkirk",
"postalCode": "FK6 6QE",
"countryName": "United Kingdom",
"streetAddress": "Cathite House 31 Winchester Avenue, Denny"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Concrete Repairs ltd"
},
"contactPoint": {
"telephone": "+44 01324821400"
}
},
{
"id": "GB-FTS-364",
"name": "Insulated Render Systems (Scotland) Limited",
"roles": [
"supplier"
],
"address": {
"region": "UKM84",
"locality": "Airdrie",
"postalCode": "ML6 9AS",
"countryName": "United Kingdom",
"streetAddress": "74 Glencraig Street, Glencraig Street"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Insulated Render Systems (Scotland) Limited"
},
"contactPoint": {
"faxNumber": "+44 01236754995",
"telephone": "+44 01236754500"
}
},
{
"id": "GB-FTS-365",
"name": "Bell Decorating Group Limited",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Airdrie",
"postalCode": "ML6 9BG",
"countryName": "United Kingdom",
"streetAddress": "Bell Business Park, Rochsolloch Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Bell Decorating Group Limited"
},
"contactPoint": {
"telephone": "+44 01689837977"
}
},
{
"id": "GB-FTS-366",
"name": "Mears Group",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Gloucester",
"postalCode": "GL3 4AH",
"countryName": "United Kingdom",
"streetAddress": "1390 Montpellier Court, Gloucester Business Park, Brockworth,"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Mears Group"
}
},
{
"id": "GB-FTS-367",
"name": "Novus Property Solutions Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Bathgate",
"postalCode": "EH48 2EP",
"countryName": "United Kingdom",
"streetAddress": "3a Inchmuir Road, Whitehill Industrial Estate, Bathgate, West Lothian"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Novus Property Solutions Ltd"
},
"contactPoint": {
"faxNumber": "+44 01782598101",
"telephone": "+44 01782598000"
}
},
{
"id": "GB-FTS-368",
"name": "McTear Contracts Ltd.",
"roles": [
"supplier"
],
"address": {
"region": "UKM84",
"locality": "WISHAW",
"postalCode": "ML2 0EG",
"countryName": "United Kingdom",
"streetAddress": "12 Canyon Road , Wishaw"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "McTear Contracts Ltd."
},
"contactPoint": {
"telephone": "+44 07454689378"
}
},
{
"id": "GB-FTS-369",
"name": "Consult Lift Services Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Paisley",
"postalCode": "PA3 2RE",
"countryName": "United Kingdom",
"streetAddress": "Thistle House, Inchinnan Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Consult Lift Services Ltd"
},
"contactPoint": {
"telephone": "+44 07788209986"
}
},
{
"id": "GB-FTS-370",
"name": "Omega Lift Services LTD",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH17 8QF",
"countryName": "United Kingdom",
"streetAddress": "Unit B1, Gracemount Business Pavilions, Captains Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Omega Lift Services LTD"
},
"contactPoint": {
"telephone": "+44 07921477767"
}
},
{
"id": "GB-FTS-371",
"name": "JGM - John G Mackintosh",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH20 9LZ",
"countryName": "United Kingdom",
"streetAddress": "30 Dryden Road, Midlothian"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "JGM - John G Mackintosh"
},
"contactPoint": {
"faxNumber": "+44 01316681611",
"telephone": "+44 01316681168"
}
},
{
"id": "GB-FTS-372",
"name": "Everwarm Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM78",
"locality": "West Lothian",
"postalCode": "EH48 2EE",
"countryName": "United Kingdom",
"streetAddress": "3 Inchcorse Place, Whitehill Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Everwarm Ltd"
},
"contactPoint": {
"telephone": "+44 07584285520"
}
},
{
"id": "GB-FTS-373",
"name": "Gas Call Services Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM82",
"locality": "Glasgow",
"postalCode": "G33 4DB",
"countryName": "United Kingdom",
"streetAddress": "2 Queenslie Court, Summerlee Street"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Gas Call Services Ltd"
},
"contactPoint": {
"faxNumber": "+44 01417746881",
"telephone": "+44 01417663333"
}
},
{
"id": "GB-FTS-374",
"name": "Dalex Systems",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Roslin",
"postalCode": "EH25 9RE",
"countryName": "United Kingdom",
"streetAddress": "Midlothian Innovation Centre, Pentlandfield"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Dalex Systems"
},
"contactPoint": {
"faxNumber": "+44 01314409076",
"telephone": "+44 01314400945"
}
},
{
"id": "GB-FTS-375",
"name": "L&D Plumbing & Tiling Services Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G33 4DZ",
"countryName": "United Kingdom",
"streetAddress": "Units 2b&c, Burntbroom Court, Queenslie Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "L&D Plumbing & Tiling Services Ltd"
},
"contactPoint": {
"faxNumber": "+44 01417743003",
"telephone": "+44 01417743111"
}
},
{
"id": "GB-FTS-376",
"name": "North SV",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Braehead",
"postalCode": "PA4 8WF",
"countryName": "United Kingdom",
"streetAddress": "Titanium 1, Kings Inch Place, King's Inch Place, Braehead"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "North SV"
},
"contactPoint": {
"telephone": "+44 03338001111"
}
},
{
"id": "GB-FTS-377",
"name": "Trident Maintenance Services",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Coatbridge",
"postalCode": "ML5 3SP",
"countryName": "United Kingdom",
"streetAddress": "Unit 12, 33 Coatbank Street"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Trident Maintenance Services"
},
"contactPoint": {
"telephone": "+44 03302020774"
}
},
{
"id": "GB-FTS-378",
"name": "Mitie Property Services (UK) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G73 1AU",
"countryName": "United Kingdom",
"streetAddress": "35 Duchess Road"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "Mitie Property Services (UK) Ltd"
},
"contactPoint": {
"telephone": "+44 07545181948"
}
},
{
"id": "GB-FTS-379",
"name": "Dem-Master Demolition Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM78",
"locality": "Bathgate",
"postalCode": "EH48 2EN",
"countryName": "United Kingdom",
"streetAddress": "4 Pottishaw Place, Whitehill Ind Est"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Dem-Master Demolition Ltd"
},
"contactPoint": {
"telephone": "+44 01506654845"
}
},
{
"id": "GB-FTS-380",
"name": "Coleman & Company Limited",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "England",
"postalCode": "B44 9ER",
"countryName": "United Kingdom",
"streetAddress": "Shady Lane, Great Barr, Birmingham"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Coleman & Company Limited"
},
"contactPoint": {
"faxNumber": "+44 01213252425",
"telephone": "+44 01213252424"
}
},
{
"id": "GB-FTS-381",
"name": "Central Demolition Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Bonnybridge",
"postalCode": "FK4 2AG",
"countryName": "United Kingdom",
"streetAddress": "Central House, Chattan Industrial Estate, Bonnyside Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Central Demolition Ltd"
},
"contactPoint": {
"faxNumber": "+44 01324815922",
"telephone": "+44 01324815700"
}
},
{
"id": "GB-FTS-382",
"name": "Daltons Demolitions Limited",
"roles": [
"supplier"
],
"address": {
"region": "UKM73",
"locality": "Edinburgh",
"postalCode": "EH12 9BU",
"countryName": "United Kingdom",
"streetAddress": "Gogarbank Iron & Steelworks, Station Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Daltons Demolitions Limited"
},
"contactPoint": {
"faxNumber": "+44 01313177168",
"telephone": "+44 01313395355"
}
},
{
"id": "GB-FTS-383",
"name": "P1 Solutions Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Edinburgh",
"postalCode": "EH6 7JQ",
"countryName": "United Kingdom",
"streetAddress": "7 Links Gardens Lane"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "P1 Solutions Ltd"
},
"contactPoint": {
"faxNumber": "+44 01315533103",
"telephone": "+44 01315554968"
}
},
{
"id": "GB-FTS-384",
"name": "Glendale Grounds Management Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKD47",
"locality": "Chorley",
"postalCode": "PR74AT",
"countryName": "United Kingdom",
"streetAddress": "The Stables, , Duxbury Hall Road, Duxbury Park,"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Glendale Grounds Management Ltd"
},
"contactPoint": {
"telephone": "+44 01257460461"
}
},
{
"id": "GB-FTS-385",
"name": "Mackenzie Construction Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G46 7TL",
"countryName": "United Kingdom",
"streetAddress": "Burnfield Avenue , Thornliebank"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Mackenzie Construction Ltd"
},
"contactPoint": {
"faxNumber": "+44 01416335656",
"telephone": "+44 01416335555"
}
},
{
"id": "GB-FTS-386",
"name": "J Sives Surfacing Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH9 3DP",
"countryName": "United Kingdom",
"streetAddress": "91b West Savile Terrace"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "J Sives Surfacing Ltd"
},
"contactPoint": {
"faxNumber": "+44 01316620411",
"telephone": "+44 01316683070"
}
},
{
"id": "GB-FTS-387",
"name": "Thomas Menzies (Builders) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Kirkcaldy",
"postalCode": "KY2 5DH",
"countryName": "United Kingdom",
"streetAddress": "Hayfield Place, Hayfield Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Thomas Menzies (Builders) Ltd"
},
"contactPoint": {
"faxNumber": "+44 015292200498",
"telephone": "+44 01592264712"
}
},
{
"id": "GB-FTS-388",
"name": "Hillhouse Quarry Group Ltd T/A MacASPHALT",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Paisley",
"postalCode": "PA2 7AN",
"countryName": "United Kingdom",
"streetAddress": "25 Scotts Road"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "Hillhouse Quarry Group Ltd T/A MacASPHALT"
},
"contactPoint": {
"telephone": "+44 01418879109"
}
},
{
"id": "GB-FTS-389",
"name": "A.C. Whyte & Co. Ltd.",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Glasgow",
"postalCode": "G78 1BF",
"countryName": "United Kingdom",
"streetAddress": "A C Whyte & Co, 6 Bowerwalls Place, Barrhead"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "A.C. Whyte & Co. Ltd."
},
"contactPoint": {
"faxNumber": "+44 01418806582",
"telephone": "+44 01418819519"
}
},
{
"id": "GB-FTS-390",
"name": "Procast Building Contractors Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM95",
"locality": "Strathaven",
"postalCode": "ML10 6LT",
"countryName": "United Kingdom",
"streetAddress": "31 Green Street"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Procast Building Contractors Ltd"
},
"contactPoint": {
"telephone": "+44 07799862737"
}
},
{
"id": "GB-FTS-391",
"name": "MP Group UK Limited",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G51 4DX",
"countryName": "United Kingdom",
"streetAddress": "324 Drumoyne Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "MP Group UK Limited"
},
"contactPoint": {
"telephone": "+44 01412371970"
}
},
{
"id": "GB-FTS-392",
"name": "SERS Energy Solutions (Scotland) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM73",
"locality": "Livingston",
"postalCode": "EH54 6TS",
"countryName": "United Kingdom",
"streetAddress": "12 Fairbairn Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "SERS Energy Solutions (Scotland) Ltd"
},
"contactPoint": {
"telephone": "+44 07917758787"
}
},
{
"id": "GB-FTS-393",
"name": "Edinburgh Sheriff Court",
"roles": [
"reviewBody"
],
"address": {
"locality": "Edinburgh",
"countryName": "United Kingdom",
"streetAddress": "Chalmers Street"
},
"details": {
"url": "http://www.edinburgh.gov.uk"
},
"identifier": {
"legalName": "Edinburgh Sheriff Court"
}
},
{
"id": "GB-FTS-394",
"name": "The City of Edinburgh Council",
"roles": [
"reviewContactPoint"
],
"address": {
"locality": "Edinburgh",
"postalCode": "EH8 8BG",
"countryName": "United Kingdom",
"streetAddress": "4 East Market Street"
},
"identifier": {
"legalName": "The City of Edinburgh Council"
}
}
],
"language": "en",
"contracts": [
{
"id": "000136-2021-1",
"title": "Electrical Works Supply and/or Install",
"value": {
"amount": 9000000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-1",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-2",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works Less than 500,000 GBP.",
"value": {
"amount": 9600000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-2",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-3",
"title": "Kitchen and Bathroom, Supply and/or Install",
"value": {
"amount": 36000000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-3",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-4",
"title": "Lift Replacement, Refurbishment and Upgrading Works - Supply and/or Install",
"value": {
"amount": 4800000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-4",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-5",
"title": "Mechanical Installations and Upgrading Works - Supply and/or Install",
"value": {
"amount": 7200000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-5",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-6",
"title": "Domestic Gas and Plumbing Installations, Supply and or Install",
"value": {
"amount": 9600000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-6",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-7",
"title": "Security - Door and Alarm Systems",
"value": {
"amount": 7200000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-7",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-8",
"title": "Painting, Decorating and Associated Preparation Works Internal and External",
"value": {
"amount": 960000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-8",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-9",
"title": "Adaptations - Ramp Installations",
"value": {
"amount": 5760000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-9",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-10",
"title": "Lead Replacement, Distribution Pipework Removal and Replacement",
"value": {
"amount": 2400000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-10",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-11",
"title": "Demolition City Wide - less than 250k GBP",
"value": {
"amount": 3600000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-11",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-12",
"title": "External Works – Neighbourhood Environmental Projects (NEPs)",
"value": {
"amount": 10080000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-12",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-13",
"title": "Demolition City Wide - less than 250k GBP",
"value": {
"amount": 2400000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-13",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-14",
"title": "Energy Efficiency",
"value": {
"amount": 30000000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-14",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-15",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works greater than 500,000 GBP",
"value": {
"amount": 60000000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-15",
"dateSigned": "2020-11-30T00:00:00Z"
}
],
"description": "This Framework will now run from 2020 to 2024 (inclusive of discretionary extension options).\n(SC Ref:638636)",
"initiationType": "tender"
}Complete JSON history (1 releases)
5 Jan 2021 · 000136-2021 · award, contract
{
"id": "000136-2021",
"tag": [
"award",
"contract"
],
"bids": {
"statistics": [
{
"id": "1",
"value": 7,
"measure": "bids",
"relatedLot": "1"
},
{
"id": "6",
"value": 9,
"measure": "bids",
"relatedLot": "2"
},
{
"id": "11",
"value": 8,
"measure": "bids",
"relatedLot": "5"
},
{
"id": "16",
"value": 3,
"measure": "bids",
"relatedLot": "6"
},
{
"id": "21",
"value": 4,
"measure": "bids",
"relatedLot": "7"
},
{
"id": "26",
"value": 5,
"measure": "bids",
"relatedLot": "8"
},
{
"id": "31",
"value": 3,
"measure": "bids",
"relatedLot": "9"
},
{
"id": "36",
"value": 5,
"measure": "bids",
"relatedLot": "10"
},
{
"id": "41",
"value": 4,
"measure": "bids",
"relatedLot": "11"
},
{
"id": "46",
"value": 3,
"measure": "bids",
"relatedLot": "12"
},
{
"id": "51",
"value": 5,
"measure": "bids",
"relatedLot": "14"
},
{
"id": "56",
"value": 7,
"measure": "bids",
"relatedLot": "16"
},
{
"id": "61",
"value": 5,
"measure": "bids",
"relatedLot": "13"
},
{
"id": "66",
"value": 9,
"measure": "bids",
"relatedLot": "15"
},
{
"id": "71",
"value": 6,
"measure": "bids",
"relatedLot": "3"
},
{
"id": "2",
"value": 7,
"measure": "smeBids",
"relatedLot": "1"
},
{
"id": "7",
"value": 9,
"measure": "smeBids",
"relatedLot": "2"
},
{
"id": "12",
"value": 8,
"measure": "smeBids",
"relatedLot": "5"
},
{
"id": "17",
"value": 3,
"measure": "smeBids",
"relatedLot": "6"
},
{
"id": "22",
"value": 4,
"measure": "smeBids",
"relatedLot": "7"
},
{
"id": "27",
"value": 3,
"measure": "smeBids",
"relatedLot": "8"
},
{
"id": "32",
"value": 3,
"measure": "smeBids",
"relatedLot": "9"
},
{
"id": "37",
"value": 4,
"measure": "smeBids",
"relatedLot": "10"
},
{
"id": "42",
"value": 4,
"measure": "smeBids",
"relatedLot": "11"
},
{
"id": "47",
"value": 3,
"measure": "smeBids",
"relatedLot": "12"
},
{
"id": "52",
"value": 4,
"measure": "smeBids",
"relatedLot": "14"
},
{
"id": "57",
"value": 6,
"measure": "smeBids",
"relatedLot": "16"
},
{
"id": "62",
"value": 4,
"measure": "smeBids",
"relatedLot": "13"
},
{
"id": "67",
"value": 9,
"measure": "smeBids",
"relatedLot": "15"
},
{
"id": "72",
"value": 6,
"measure": "smeBids",
"relatedLot": "3"
},
{
"id": "3",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "1"
},
{
"id": "8",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "2"
},
{
"id": "13",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "5"
},
{
"id": "18",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "6"
},
{
"id": "23",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "7"
},
{
"id": "28",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "8"
},
{
"id": "33",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "9"
},
{
"id": "38",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "10"
},
{
"id": "43",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "11"
},
{
"id": "48",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "12"
},
{
"id": "53",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "14"
},
{
"id": "58",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "16"
},
{
"id": "63",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "13"
},
{
"id": "68",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "15"
},
{
"id": "73",
"value": 0,
"measure": "foreignBidsFromEU",
"relatedLot": "3"
},
{
"id": "4",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "1"
},
{
"id": "9",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "2"
},
{
"id": "14",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "5"
},
{
"id": "19",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "6"
},
{
"id": "24",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "7"
},
{
"id": "29",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "8"
},
{
"id": "34",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "9"
},
{
"id": "39",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "10"
},
{
"id": "44",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "11"
},
{
"id": "49",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "12"
},
{
"id": "54",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "14"
},
{
"id": "59",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "16"
},
{
"id": "64",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "13"
},
{
"id": "69",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "15"
},
{
"id": "74",
"value": 0,
"measure": "foreignBidsFromNonEU",
"relatedLot": "3"
},
{
"id": "5",
"value": 7,
"measure": "electronicBids",
"relatedLot": "1"
},
{
"id": "10",
"value": 9,
"measure": "electronicBids",
"relatedLot": "2"
},
{
"id": "15",
"value": 8,
"measure": "electronicBids",
"relatedLot": "5"
},
{
"id": "20",
"value": 3,
"measure": "electronicBids",
"relatedLot": "6"
},
{
"id": "25",
"value": 4,
"measure": "electronicBids",
"relatedLot": "7"
},
{
"id": "30",
"value": 5,
"measure": "electronicBids",
"relatedLot": "8"
},
{
"id": "35",
"value": 3,
"measure": "electronicBids",
"relatedLot": "9"
},
{
"id": "40",
"value": 5,
"measure": "electronicBids",
"relatedLot": "10"
},
{
"id": "45",
"value": 4,
"measure": "electronicBids",
"relatedLot": "11"
},
{
"id": "50",
"value": 3,
"measure": "electronicBids",
"relatedLot": "12"
},
{
"id": "55",
"value": 5,
"measure": "electronicBids",
"relatedLot": "14"
},
{
"id": "60",
"value": 7,
"measure": "electronicBids",
"relatedLot": "16"
},
{
"id": "65",
"value": 5,
"measure": "electronicBids",
"relatedLot": "13"
},
{
"id": "70",
"value": 9,
"measure": "electronicBids",
"relatedLot": "15"
},
{
"id": "75",
"value": 6,
"measure": "electronicBids",
"relatedLot": "3"
}
]
},
"date": "2021-01-05T15:16:04Z",
"ocid": "ocds-h6vhtk-0287ce",
"buyer": {
"id": "GB-FTS-346",
"name": "The City of Edinburgh Council"
},
"links": [
{
"rel": "prev",
"href": "https://ted.europa.eu/udl?uri=TED:NOTICE:161372-2019:TEXT:EN:HTML"
}
],
"awards": [
{
"id": "000136-2021-1",
"title": "Electrical Works Supply and/or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-347",
"name": "Maclin Electric Ltd"
},
{
"id": "GB-FTS-358",
"name": "Nicholson Bros (Electrical Contractors) Ltd"
},
{
"id": "GB-FTS-359",
"name": "G D Chalmers Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-351",
"name": "T B Mackay Energy Services Ltd"
},
{
"id": "GB-FTS-352",
"name": "Easy Heat Systems Ltd"
},
{
"id": "GB-FTS-360",
"name": "OpenView Security Solutions Ltd"
},
{
"id": "GB-FTS-361",
"name": "Belac Group Limited"
}
],
"relatedLots": [
"1"
]
},
{
"id": "000136-2021-2",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works Less than 500,000 GBP.",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-348",
"name": "Morris & Spottiswood"
},
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited"
},
{
"id": "GB-FTS-362",
"name": "Apex Developments Ltd"
},
{
"id": "GB-FTS-363",
"name": "Concrete Repairs ltd"
},
{
"id": "GB-FTS-357",
"name": "Ailsa Building Contractors Ltd"
},
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-364",
"name": "Insulated Render Systems (Scotland) Limited"
},
{
"id": "GB-FTS-365",
"name": "Bell Decorating Group Limited"
}
],
"relatedLots": [
"2"
]
},
{
"id": "000136-2021-3",
"title": "Kitchen and Bathroom, Supply and/or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-365",
"name": "Bell Decorating Group Limited"
},
{
"id": "GB-FTS-366",
"name": "Mears Group"
},
{
"id": "GB-FTS-367",
"name": "Novus Property Solutions Ltd"
},
{
"id": "GB-FTS-361",
"name": "Belac Group Limited"
},
{
"id": "GB-FTS-368",
"name": "McTear Contracts Ltd."
}
],
"relatedLots": [
"5"
]
},
{
"id": "000136-2021-4",
"title": "Lift Replacement, Refurbishment and Upgrading Works - Supply and/or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-350",
"name": "Caltech Lifts Ltd"
},
{
"id": "GB-FTS-369",
"name": "Consult Lift Services Ltd"
},
{
"id": "GB-FTS-370",
"name": "Omega Lift Services LTD"
}
],
"relatedLots": [
"6"
]
},
{
"id": "000136-2021-5",
"title": "Mechanical Installations and Upgrading Works - Supply and/or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-351",
"name": "T B Mackay Energy Services Ltd"
},
{
"id": "GB-FTS-352",
"name": "Easy Heat Systems Ltd"
},
{
"id": "GB-FTS-371",
"name": "JGM - John G Mackintosh"
}
],
"relatedLots": [
"7"
]
},
{
"id": "000136-2021-6",
"title": "Domestic Gas and Plumbing Installations, Supply and or Install",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-352",
"name": "Easy Heat Systems Ltd"
},
{
"id": "GB-FTS-372",
"name": "Everwarm Ltd"
},
{
"id": "GB-FTS-373",
"name": "Gas Call Services Ltd"
},
{
"id": "GB-FTS-374",
"name": "Dalex Systems"
},
{
"id": "GB-FTS-375",
"name": "L&D Plumbing & Tiling Services Ltd"
}
],
"relatedLots": [
"8"
]
},
{
"id": "000136-2021-7",
"title": "Security - Door and Alarm Systems",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-353",
"name": "Eden Group"
},
{
"id": "GB-FTS-360",
"name": "OpenView Security Solutions Ltd"
},
{
"id": "GB-FTS-376",
"name": "North SV"
}
],
"relatedLots": [
"9"
]
},
{
"id": "000136-2021-8",
"title": "Painting, Decorating and Associated Preparation Works Internal and External",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-365",
"name": "Bell Decorating Group Limited"
},
{
"id": "GB-FTS-367",
"name": "Novus Property Solutions Ltd"
},
{
"id": "GB-FTS-377",
"name": "Trident Maintenance Services"
},
{
"id": "GB-FTS-378",
"name": "Mitie Property Services (UK) Ltd"
}
],
"relatedLots": [
"10"
]
},
{
"id": "000136-2021-9",
"title": "Adaptations - Ramp Installations",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited"
},
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-351",
"name": "T B Mackay Energy Services Ltd"
}
],
"relatedLots": [
"11"
]
},
{
"id": "000136-2021-10",
"title": "Lead Replacement, Distribution Pipework Removal and Replacement",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-361",
"name": "Belac Group Limited"
}
],
"relatedLots": [
"12"
]
},
{
"id": "000136-2021-11",
"title": "Demolition City Wide - less than 250k GBP",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-356",
"name": "JCJ Demolition and Construction Ltd"
},
{
"id": "GB-FTS-379",
"name": "Dem-Master Demolition Ltd"
},
{
"id": "GB-FTS-380",
"name": "Coleman & Company Limited"
},
{
"id": "GB-FTS-381",
"name": "Central Demolition Ltd"
},
{
"id": "GB-FTS-382",
"name": "Daltons Demolitions Limited"
}
],
"relatedLots": [
"14"
]
},
{
"id": "000136-2021-12",
"title": "External Works – Neighbourhood Environmental Projects (NEPs)",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited"
},
{
"id": "GB-FTS-383",
"name": "P1 Solutions Ltd"
},
{
"id": "GB-FTS-384",
"name": "Glendale Grounds Management Ltd"
},
{
"id": "GB-FTS-385",
"name": "Mackenzie Construction Ltd"
},
{
"id": "GB-FTS-386",
"name": "J Sives Surfacing Ltd"
},
{
"id": "GB-FTS-387",
"name": "Thomas Menzies (Builders) Ltd"
},
{
"id": "GB-FTS-388",
"name": "Hillhouse Quarry Group Ltd T/A MacASPHALT"
}
],
"relatedLots": [
"16"
]
},
{
"id": "000136-2021-13",
"title": "Demolition City Wide - less than 250k GBP",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-356",
"name": "JCJ Demolition and Construction Ltd"
},
{
"id": "GB-FTS-379",
"name": "Dem-Master Demolition Ltd"
},
{
"id": "GB-FTS-380",
"name": "Coleman & Company Limited"
},
{
"id": "GB-FTS-381",
"name": "Central Demolition Ltd"
},
{
"id": "GB-FTS-382",
"name": "Daltons Demolitions Limited"
}
],
"relatedLots": [
"13"
]
},
{
"id": "000136-2021-14",
"title": "Energy Efficiency",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-357",
"name": "Ailsa Building Contractors Ltd"
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services"
},
{
"id": "GB-FTS-364",
"name": "Insulated Render Systems (Scotland) Limited"
},
{
"id": "GB-FTS-389",
"name": "A.C. Whyte & Co. Ltd."
},
{
"id": "GB-FTS-372",
"name": "Everwarm Ltd"
},
{
"id": "GB-FTS-390",
"name": "Procast Building Contractors Ltd"
},
{
"id": "GB-FTS-391",
"name": "MP Group UK Limited"
},
{
"id": "GB-FTS-392",
"name": "SERS Energy Solutions (Scotland) Ltd"
}
],
"relatedLots": [
"15"
]
},
{
"id": "000136-2021-15",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works greater than 500,000 GBP",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-348",
"name": "Morris & Spottiswood"
},
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited"
},
{
"id": "GB-FTS-363",
"name": "Concrete Repairs ltd"
},
{
"id": "GB-FTS-357",
"name": "Ailsa Building Contractors Ltd"
},
{
"id": "GB-FTS-364",
"name": "Insulated Render Systems (Scotland) Limited"
},
{
"id": "GB-FTS-389",
"name": "A.C. Whyte & Co. Ltd."
}
],
"relatedLots": [
"3"
]
}
],
"tender": {
"id": "ocds-h6vhtk-0287ce",
"lots": [
{
"id": "3",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works greater than 500,000 GBP",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nRoofing:\nPlumbing/Drainage:\nAdaptations:\nPest control:\nStructures:\nOther adhoc works\nCondition Surveys\nSustainable Energy:\nProfessional Services:\nTrades: Not limited to\nPlastering - All forms of traditional and non-traditional plastering, including localised repairs and full room fit out replacement\nJoinery - All forms of joinery as required\nElectrician – minor and major electrical works\nPlease refer to Schedule 1 Lot 3 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "2",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works Less than 500,000 GBP.",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nRoofing:\nPlumbing/Drainage:\nAdaptations:\nPest control:\nStructures:\nOther adhoc works\nCondition Surveys\nSustainable Energy:\nProfessional Services:\nTrades: Not limited to\nPlastering - All forms of traditional and non-traditional plastering, including localised repairs and full room fit out replacement\nJoinery - All forms of joinery as required\nElectrician – minor and major electrical works\nPlease refer to Schedule 1 Lot 2 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "5",
"title": "Kitchen and Bathroom, Supply and/or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nSupply and/or install Kitchens and bathrooms including design\nOther adhoc works\nCondition Surveys\nProfessional Services:\nTrades: Not limited to\nJoinery - All forms of joinery as required\nElectrician\nPlumber\nGas Engineer\nPlasterer\nPlease refer to Schedule 1 Lot 5 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "16",
"title": "External Works – Neighbourhood Environmental Projects (NEPs)",
"status": "cancelled",
"hasOptions": false,
"description": "Works consist of a series of undefined, external refurbishment and upgrading projects on Council land.\nIt is anticipated that most projects will be with neighbourhoods but could be anywhere in the Councils portfolio of land.\nWorks will be carried out in consultation with the client(CEC), community groups, owners, tenants, and members of the public, and the contractor may on occasion be required to attend briefings with council staff/local community groups/elected members.\nWork will consist of the following but not limited to:\nRemoval of debris in line with environmental legislation.\nSite security and safety measures.\nLiaising with appropriate utility companies to arrange appropriate licenses, permit and agreement to carry out works. – where possible specifics will be set out in mini tender documents. All discussions surrounding utilities unknown until works began, must be led by the Contractor.\nEnsure traffic management systems, including road closures are in place and agreed with Locality prior to commencement of works, where applicable.\nEnsure appropriate signage is in place to inform residents of works, safety and start and end dates of works.\nHot works permits for all appropriate works.\nTemporary work solutions, shoring, propping, protection.\nSite clearance, cleaning, reinstatement to original state/condition.\nRepair/removal/replacement/installation works relating to landscaping, fencing, drainage, earthworks, geotechnical, piling and underpinning.\nRepair/removal/replacement/installation works relating to play areas and play/exercise equipment etc.\nRepair/removal/replacement/installation works relating to concrete structures.\nRepair/removal/replacement of roads/paths and the like\nUndertaking and provision of testing/reporting.\nInstallation of structural supports/repairs/strengthening as directed.\nSite investigations and reports where required.\nWaste removal and site clear up.\nOther ad hoc and associated works.\nPlease refer to Schedule 1 Lot 16 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "8",
"title": "Domestic Gas and Plumbing Installations, Supply and or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nGenerally, the work will consist of - Supply and/or Install replacement or upgrading of:\nGas Boiler Replacements (maybe issued by CEC)\nRadiator Replacements\nHeating and distribution Pipework.\nHot Water Storage Cylinder Replacements\nFull Central Heating System Replacements and upgrades\nControls Upgrades and Replacements.\nDomestic components related to renewable heating technologies.\nAttendance to Defects and Failures (Generally within defects period)\nDomestic Hot Water (DHW), Domestic Cold Water (DCW) and Mains Cold Water (MCW) distribution pipework, storage systems, pumps and control systems and drainage systems.\nPlease refer to Schedule 1 Lot 8 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "6",
"title": "Lift Replacement, Refurbishment and Upgrading Works - Supply and/or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nDesign, Supply and or Installation of Refurbishments, Upgrades or New Electronic Passenger Lift Car/Cars (including Machine, Controllers & Drive, Overspeed Governor, Lift Car & Sling, Landing Entrance including Push Buttons & Indicators, sundries. This may or may not include Guides & Counterweights) within existing buildings. Including, delivery (including off-loading), dismantling and removal of the equivalent existing equipment, and all necessary and associated skills and trades.\nTesting and identification of all beams, handling and lifting equipment.\nThe dismantling and safe removal and disposal of the equivalent existing equipment.\nPlease refer to Schedule 1 Lot 6 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "7",
"title": "Mechanical Installations and Upgrading Works - Supply and/or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic and commercial Properties, although there may be a need to carry out works in mixed tenure and other building types as the need arises.\nThe remit of this contract will require contractors to replace commercial installations which may include some forms of electrical control equipment (BMS)\nGenerally, the work will consist of the replacement or upgrading of:\nCommercial Heating/Hot Water Systems:\nUpgrading/replacement or maintenance of commercial heating/hot water systems within commercial properties and domestic properties including multi storey blocks; including all associated boilers (all fuels), plant & equipment, calorifiers & storage tanks, pipework, pumps & valves, heat emitters, trace heating and management systems etc.\nAOV Systems (Automatic Opening Vent):\nUpgrading/replacement or maintenance of AOV systems within commercial properties and multi storey blocks, including all associated control panels, cabling, components, smoke detectors, control systems and routine testing and maintenance as required etc.\nVentilation Systems:\nUpgrading/replacement or maintenance of commercial ventilation systems within commercial properties and domestic properties including multi storey blocks; including all associated plant & equipment, pipework, pumps & valves, fans, heating elements, HVAC systems and management systems etc.\nFire Suppression & Sprinkler Systems:\nUpgrading/replacement or maintenance of fire suppression & sprinkler systems within\ncommercial properties and domestic properties including multi storey blocks; including all associated plant & equipment, pipework, pumps & valves, dry risers and management systems etc.\nGenerators:\nUpgrading/replacement or maintenance of generators / mobile generators for commercial properties and domestic properties including multi storey blocks; including all associated plant, equipment and management/control systems etc.\nPlease refer to Schedule 1 Lot 7 for further information on the scope of this Lot\nThis lot is broken in to sub lots\n1.1 Commercial Heating/Hot Water Systems\n1.2 AOV Systems (Automatic Opening Vent)\n1.3 Ventilation Systems\n1.4 Fire Suppression & Sprinkler Systems\n1.5 Generators",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "9",
"title": "Security - Door and Alarm Systems",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nGenerally, the work will consist of - Supply and/or Install replacement or upgrading of:\nDoor Entry:\nInstallation of an electronically controlled door entry system to be activated from handsets within individual flats.\nCCTV Systems:\nInstallation of CCTV systems, including the removal, disposal and replacement or repair of existing systems.\nWorks shall include the removal, disposal and replacement or repair of existing systems\nAll existing electronic infrastructure shall be checked and upgraded as appropriate.\nWarden Call Systems:\nInstallation of Warden Call Systems, including the removal, disposal and replacement or repair of existing systems. All existing electronic infrastructure shall be checked and upgraded as appropriate.\nInstallation of individual bespoke systems for particularly vulnerable or disabled tenants.\nInstallations of grouped systems, combined warden call systems and dispersed alarms.\nCommunal TV / Satellite Systems (Passive & Active):\nInstallation of communal TV, Satellite and Integrated Reception Systems (IRS) systems, including the repair or removal, disposal and replacement of existing systems.\nAll existing electronic infrastructure shall be checked and upgraded as appropriate.\nPlease refer to Schedule 1 Lot 9 for further information on the scope of this Lot\nThis lot is broken in to sub lots\n1.1 Secure Door Entry Systems\n1.2 CCTV Systems\n1.3 Warden Call Systems\n1.4 Communal TV/Satellite/IRS Systems",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "15",
"title": "Energy Efficiency",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nInternal wall insulation:\nDraught proofing of doors and windows\nInstalling under floor insulation\nInstalling insulated flat roof system Installing insulated plasterboard to internal walls and ceilings\nExternal wall insulation:\nApplying appropriate insulation material to exposed concrete areas, such as garages and exposed under-croft ceiling spaces\nDraught proofing of doors and windows\nInstalling External Wall Insulation systems\nLoft insulation:\nInsulating of pipe work in lofts and under floors\nInstalling roof vents in loft spaces\nInstalling or topping up loft insulation\nRelaying of damaged/missing loft insulation\nCavity Wall Insulation:\nCarrying out cavity wall insulation installation or extract/refill of defective insulation\nSustainable Energy:\nInstalling Solar PV or Solar Hot Water systems\nProvide the appropriately qualified and experienced trades for enabling works that include, electricians, joiners, gas engineers, plumbers and painters\nEPC Certification (Energy Performance Certificate):\nVisiting tenants in their homes and carrying out energy surveys which also identify any other defects with the property that may impact on the installation of any insulation measures\nProducing an ‘Energy Survey Report’ for CEC identifying any insulation requirements that includes both U-value and Dew Point calculations\nProducing SAP reports or Energy Performance Certificate (EPC) lodged with the Scottish EPC register before and/or after installation of the measure as instructed\nCarry out monitoring of the effectiveness of installed measures in tenant’s property\nPlease refer to Schedule 1 Lot 15 for further information on the scope of this Lot\nThis lot is broken in to sub lots\n1.1 Internal Wall Insulation\n1.2 External wall insulation\n1.3 Loft Insulation\n1.4 Cavity Wall Insulation\n1.5 Sustainable Energy\n1.6 Energy Performance Certification",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "10",
"title": "Painting, Decorating and Associated Preparation Works Internal and External",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nWorks could include: but not limited to\nPreparation and Decoration to External Render/Bick/Block Walls\nPreparation and Decoration to Common Stairs Walls & Ceilings (fire retardant and anti-graffiti systems may be required)\nPreparation and Decoration to External Fascia’s, Bargeboards, eaves etc. Preparation and Decoration to High Rise Drying Areas\nPlease refer to Schedule 1 Lot 10 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "14",
"title": "Demolition City Wide - less than 250k GBP",
"status": "cancelled",
"hasOptions": false,
"description": "The works shall include safe and controlled and emergency demolition of commercial and domestic Buildings, including demolition by explosives of non-traditional and traditional high and low rise structures within the domestic and non-domestic sectors and removal of all debris arising.\nSafe removal and excavation of foundations, substructure fill material including contaminated materials, underground services and removal of all debris arising.\nSite reinstatement shall be required including bringing to site imported fill material and/or selected crush material arising from the demolitions together with top soiling and seeding and the provision of long and short term fencing of completed sites including signage.\nOn occasions contractors will be expected to respond to a requirement for a structure to be demolished at short notice.\nCo-operate with all power/gas/IT/utility providers, external consultants, police/emergency services, all other council and private ‘neighbours’\nCo-operate with city archaeologist if required\nShall act as Principal Contractor (CDMC) and produce all relevant forms/information.\nCompliance with H&S, Asbestos removal\nContractors shall be a licensed to remove asbestos and be members of a recognised registration body such as NFDC for the duration of the framework contract.\nAll other adhoc associated works.\nPlease refer to Schedule 1 Lot 14 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "11",
"title": "Adaptations - Ramp Installations",
"status": "cancelled",
"hasOptions": false,
"description": "The successful Contractor/s will be required to supply and/or install permeant or temporary ramps at predominately domestic properties throughout the Councils estate, as and when identified by the Council representatives.\nIn addition, there may be a requirement to dismantle and or reinstall existing equipment at new locations, as and when identified by the Council.\nPermanent and temporary ramps may be fabricated in metal or constructed in\nbrick/block and concrete.\nAll ramps must comply with all regulations, be constructed to the correct gradient for the available distance, have all the necessary platforms/landings/steps and handrails as required, be non-slip etc., additional steps/plats: to be constructed with brick/block and concrete, any additional handrails etc. which may be installed at existing or new steps\nAll the above to allow access to dwellings/buildings, all in compliance with Disability Discrimination Act (DDA) Regulations.\nAn element of contractor’s design will be required.\nAll other adhoc works\nPlease refer to Schedule 1 Lot 11 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "13",
"title": "Demolition City Wide - less than 250k GBP",
"status": "cancelled",
"hasOptions": false,
"description": "The works shall include safe and controlled and emergency demolition of commercial and domestic Buildings, including demolition by explosives of non-traditional and traditional high and low rise structures within the domestic and non-domestic sectors and removal of all debris arising.\nSafe removal and excavation of foundations, substructure fill material including contaminated materials, underground services and removal of all debris arising.\nSite reinstatement shall be required including bringing to site imported fill material and/or selected crush material arising from the demolitions together with top soiling and seeding and the provision of long and short term fencing of completed sites including signage.\nOn occasions contractors will be expected to respond to a requirement for a structure to be demolished at short notice.\nCo-operate with all power/gas/IT/utility providers, external consultants, police/emergency services, all other council and private ‘neighbours’\nCo-operate with city archaeologist if required\nShall act as Principal Contractor (CDMC) and produce all relevant forms/information.\nCompliance with H&S, Asbestos removal\nContractors shall be a licensed to remove asbestos and be members of a recognised registration body such as NFDC for the duration of the framework contract.\nAll other adhoc associated works.\nPlease refer to Schedule 1 Lot 13 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "12",
"title": "Lead Replacement, Distribution Pipework Removal and Replacement",
"status": "cancelled",
"hasOptions": false,
"description": "Works will be carried out to private supply pipework located within and connected to Mains Distribution pipe work in and around traditional and non-traditional high and low rise domestic and commercial properties.\nThe work will include, but not be limited to;\nThe removal & safe disposal of all existing lead pipework\nThe replacement of the lead pipework with new copper pipework to hot and cold supply systems including all valves/accessories and sundries required,\nFlushing, filling & commissioning pipes/cisterns and all associated testing and certification,\nEarthing and all associated testing & certification.\nPipework insulation,\nNew cisterns for potable water as required,\nBuilder work in connection with, hot and cold supply pipes,\nUnderground plastic/clay pipework including all tapes/bedding/surrounds and haunching, making good roadways/pedestrian pavements,\nPlease refer to Schedule 1 Lot 12 for further information on the scope of this Lot",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "cost",
"type": "cost",
"description": "60"
}
]
}
},
{
"id": "1",
"title": "Electrical Works Supply and/or Install",
"status": "cancelled",
"hasOptions": false,
"description": "Predominantly the work will be carried out in traditional and non-traditional Low and High Rise Domestic Properties, although there may be a need to carry out works in mixed tenure and commercial properties/building as the need arises.\nBrief scope\nElectrical refit/rewire\nElectric Heating\nFire/Smoke Detection\nEmergency Lighting Systems\nAdhoc works\nthis lot is broken in to sub lots",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "40"
},
{
"name": "Cost",
"type": "cost",
"description": "60"
}
]
}
}
],
"items": [
{
"id": "3",
"relatedLot": "3",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "44220000",
"scheme": "CPV",
"description": "Builders' joinery"
},
{
"id": "45420000",
"scheme": "CPV",
"description": "Joinery and carpentry installation work"
},
{
"id": "45421000",
"scheme": "CPV",
"description": "Joinery work"
},
{
"id": "45421140",
"scheme": "CPV",
"description": "Installation of metal joinery except doors and windows"
},
{
"id": "45421150",
"scheme": "CPV",
"description": "Non-metal joinery installation work"
},
{
"id": "45311000",
"scheme": "CPV",
"description": "Electrical wiring and fitting work"
},
{
"id": "45311100",
"scheme": "CPV",
"description": "Electrical wiring work"
},
{
"id": "45311200",
"scheme": "CPV",
"description": "Electrical fitting work"
},
{
"id": "45315100",
"scheme": "CPV",
"description": "Electrical engineering installation works"
},
{
"id": "45317000",
"scheme": "CPV",
"description": "Other electrical installation work"
},
{
"id": "45310000",
"scheme": "CPV",
"description": "Electrical installation work"
},
{
"id": "45315000",
"scheme": "CPV",
"description": "Electrical installation work of heating and other electrical building-equipment"
},
{
"id": "45421100",
"scheme": "CPV",
"description": "Installation of doors and windows and related components"
},
{
"id": "45421110",
"scheme": "CPV",
"description": "Installation of door and window frames"
},
{
"id": "45421112",
"scheme": "CPV",
"description": "Installation of window frames"
},
{
"id": "45421132",
"scheme": "CPV",
"description": "Installation of windows"
},
{
"id": "45421151",
"scheme": "CPV",
"description": "Installation of fitted kitchens"
},
{
"id": "45211310",
"scheme": "CPV",
"description": "Bathrooms construction work"
},
{
"id": "45211000",
"scheme": "CPV",
"description": "Construction work for multi-dwelling buildings and individual houses"
},
{
"id": "51120000",
"scheme": "CPV",
"description": "Installation services of mechanical equipment"
},
{
"id": "51111200",
"scheme": "CPV",
"description": "Installation services of generators"
},
{
"id": "51100000",
"scheme": "CPV",
"description": "Installation services of electrical and mechanical equipment"
},
{
"id": "45350000",
"scheme": "CPV",
"description": "Mechanical installations"
},
{
"id": "45351000",
"scheme": "CPV",
"description": "Mechanical engineering installation works"
},
{
"id": "71314000",
"scheme": "CPV",
"description": "Energy and related services"
},
{
"id": "45442100",
"scheme": "CPV",
"description": "Painting work"
},
{
"id": "45442110",
"scheme": "CPV",
"description": "Painting work of buildings"
},
{
"id": "45442120",
"scheme": "CPV",
"description": "Painting and protective-coating work of structures"
},
{
"id": "44230000",
"scheme": "CPV",
"description": "Builders' carpentry"
},
{
"id": "45443000",
"scheme": "CPV",
"description": "Facade work"
},
{
"id": "45410000",
"scheme": "CPV",
"description": "Plastering work"
}
]
},
{
"id": "2",
"relatedLot": "2",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45260000",
"scheme": "CPV",
"description": "Roof works and other special trade construction works"
},
{
"id": "45262000",
"scheme": "CPV",
"description": "Special trade construction works other than roof works"
},
{
"id": "44220000",
"scheme": "CPV",
"description": "Builders' joinery"
},
{
"id": "45420000",
"scheme": "CPV",
"description": "Joinery and carpentry installation work"
},
{
"id": "45421150",
"scheme": "CPV",
"description": "Non-metal joinery installation work"
},
{
"id": "45421140",
"scheme": "CPV",
"description": "Installation of metal joinery except doors and windows"
},
{
"id": "09300000",
"scheme": "CPV",
"description": "Electricity, heating, solar and nuclear energy"
},
{
"id": "45311000",
"scheme": "CPV",
"description": "Electrical wiring and fitting work"
},
{
"id": "45311100",
"scheme": "CPV",
"description": "Electrical wiring work"
},
{
"id": "45311200",
"scheme": "CPV",
"description": "Electrical fitting work"
},
{
"id": "45315100",
"scheme": "CPV",
"description": "Electrical engineering installation works"
},
{
"id": "45317000",
"scheme": "CPV",
"description": "Other electrical installation work"
},
{
"id": "45310000",
"scheme": "CPV",
"description": "Electrical installation work"
},
{
"id": "45315000",
"scheme": "CPV",
"description": "Electrical installation work of heating and other electrical building-equipment"
},
{
"id": "45421100",
"scheme": "CPV",
"description": "Installation of doors and windows and related components"
},
{
"id": "45421110",
"scheme": "CPV",
"description": "Installation of door and window frames"
},
{
"id": "45421112",
"scheme": "CPV",
"description": "Installation of window frames"
},
{
"id": "45421130",
"scheme": "CPV",
"description": "Installation of doors and windows"
},
{
"id": "45421132",
"scheme": "CPV",
"description": "Installation of windows"
},
{
"id": "45421151",
"scheme": "CPV",
"description": "Installation of fitted kitchens"
},
{
"id": "45211310",
"scheme": "CPV",
"description": "Bathrooms construction work"
},
{
"id": "45211000",
"scheme": "CPV",
"description": "Construction work for multi-dwelling buildings and individual houses"
},
{
"id": "51120000",
"scheme": "CPV",
"description": "Installation services of mechanical equipment"
},
{
"id": "51111200",
"scheme": "CPV",
"description": "Installation services of generators"
},
{
"id": "51100000",
"scheme": "CPV",
"description": "Installation services of electrical and mechanical equipment"
},
{
"id": "45350000",
"scheme": "CPV",
"description": "Mechanical installations"
},
{
"id": "45351000",
"scheme": "CPV",
"description": "Mechanical engineering installation works"
},
{
"id": "71314000",
"scheme": "CPV",
"description": "Energy and related services"
},
{
"id": "45442100",
"scheme": "CPV",
"description": "Painting work"
},
{
"id": "45442110",
"scheme": "CPV",
"description": "Painting work of buildings"
},
{
"id": "45442120",
"scheme": "CPV",
"description": "Painting and protective-coating work of structures"
},
{
"id": "44230000",
"scheme": "CPV",
"description": "Builders' carpentry"
},
{
"id": "45443000",
"scheme": "CPV",
"description": "Facade work"
},
{
"id": "45410000",
"scheme": "CPV",
"description": "Plastering work"
}
]
},
{
"id": "5",
"relatedLot": "5",
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45211310",
"scheme": "CPV",
"description": "Bathrooms construction work"
},
{
"id": "45421151",
"scheme": "CPV",
"description": "Installation of fitted kitchens"
},
{
"id": "44410000",
"scheme": "CPV",
"description": "Articles for the bathroom and kitchen"
},
{
"id": "39141400",
"scheme": "CPV",
"description": "Fitted kitchens"
}
]
},
{
"id": "16",
"relatedLot": "16",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45111240",
"scheme": "CPV",
"description": "Ground-drainage work"
},
{
"id": "45112720",
"scheme": "CPV",
"description": "Landscaping work for sports grounds and recreational areas"
},
{
"id": "45112723",
"scheme": "CPV",
"description": "Landscaping work for playgrounds"
},
{
"id": "45212221",
"scheme": "CPV",
"description": "Construction work in connection with structures for sports ground"
},
{
"id": "71421000",
"scheme": "CPV",
"description": "Landscape gardening services"
},
{
"id": "71400000",
"scheme": "CPV",
"description": "Urban planning and landscape architectural services"
}
]
},
{
"id": "8",
"relatedLot": "8",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "39715000",
"scheme": "CPV",
"description": "Water heaters and heating for buildings; plumbing equipment"
},
{
"id": "39715200",
"scheme": "CPV",
"description": "Heating equipment"
},
{
"id": "42160000",
"scheme": "CPV",
"description": "Boiler installations"
},
{
"id": "44620000",
"scheme": "CPV",
"description": "Central-heating radiators and boilers and parts"
},
{
"id": "44621000",
"scheme": "CPV",
"description": "Radiators and boilers"
},
{
"id": "44621200",
"scheme": "CPV",
"description": "Boilers"
},
{
"id": "44621210",
"scheme": "CPV",
"description": "Water boilers"
},
{
"id": "42161000",
"scheme": "CPV",
"description": "Hot-water boilers"
},
{
"id": "39721410",
"scheme": "CPV",
"description": "Gas appliances"
}
]
},
{
"id": "6",
"relatedLot": "6",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45313100",
"scheme": "CPV",
"description": "Lift installation work"
},
{
"id": "45313000",
"scheme": "CPV",
"description": "Lift and escalator installation work"
},
{
"id": "51511100",
"scheme": "CPV",
"description": "Installation services of lifting equipment"
},
{
"id": "42416100",
"scheme": "CPV",
"description": "Lifts"
},
{
"id": "42416120",
"scheme": "CPV",
"description": "Goods lifts"
},
{
"id": "42416130",
"scheme": "CPV",
"description": "Mechanical lifts"
},
{
"id": "50750000",
"scheme": "CPV",
"description": "Lift-maintenance services"
}
]
},
{
"id": "7",
"relatedLot": "7",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45310000",
"scheme": "CPV",
"description": "Electrical installation work"
},
{
"id": "31100000",
"scheme": "CPV",
"description": "Electric motors, generators and transformers"
},
{
"id": "31120000",
"scheme": "CPV",
"description": "Generators"
},
{
"id": "31122000",
"scheme": "CPV",
"description": "Generator units"
},
{
"id": "31127000",
"scheme": "CPV",
"description": "Emergency generator"
},
{
"id": "39563530",
"scheme": "CPV",
"description": "Ventilation ducting"
},
{
"id": "42500000",
"scheme": "CPV",
"description": "Cooling and ventilation equipment"
},
{
"id": "42520000",
"scheme": "CPV",
"description": "Ventilation equipment"
},
{
"id": "45331000",
"scheme": "CPV",
"description": "Heating, ventilation and air-conditioning installation work"
},
{
"id": "45331200",
"scheme": "CPV",
"description": "Ventilation and air-conditioning installation work"
},
{
"id": "45331211",
"scheme": "CPV",
"description": "Outdoor ventilation installation work"
},
{
"id": "71315410",
"scheme": "CPV",
"description": "Inspection of ventilation system"
},
{
"id": "35111500",
"scheme": "CPV",
"description": "Fire suppression system"
},
{
"id": "35111510",
"scheme": "CPV",
"description": "Fire suppression hand tools"
},
{
"id": "35111520",
"scheme": "CPV",
"description": "Fire suppression foam or similar compounds"
},
{
"id": "09321000",
"scheme": "CPV",
"description": "Hot water"
},
{
"id": "45311200",
"scheme": "CPV",
"description": "Electrical fitting work"
},
{
"id": "45311100",
"scheme": "CPV",
"description": "Electrical wiring work"
},
{
"id": "45311000",
"scheme": "CPV",
"description": "Electrical wiring and fitting work"
},
{
"id": "44621111",
"scheme": "CPV",
"description": "Non-electrically-heated central-heating radiators"
},
{
"id": "44111530",
"scheme": "CPV",
"description": "Electrical insulating fittings"
},
{
"id": "44111511",
"scheme": "CPV",
"description": "Electrical insulators"
},
{
"id": "45315000",
"scheme": "CPV",
"description": "Electrical installation work of heating and other electrical building-equipment"
},
{
"id": "45315100",
"scheme": "CPV",
"description": "Electrical engineering installation works"
},
{
"id": "45317100",
"scheme": "CPV",
"description": "Electrical installation work of pumping equipment"
},
{
"id": "45317200",
"scheme": "CPV",
"description": "Electrical installation work of transformers"
},
{
"id": "71334000",
"scheme": "CPV",
"description": "Mechanical and electrical engineering services"
},
{
"id": "71323100",
"scheme": "CPV",
"description": "Electrical power systems design services"
},
{
"id": "51100000",
"scheme": "CPV",
"description": "Installation services of electrical and mechanical equipment"
}
]
},
{
"id": "9",
"relatedLot": "9",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "35125300",
"scheme": "CPV",
"description": "Security cameras"
},
{
"id": "35121300",
"scheme": "CPV",
"description": "Security fittings"
},
{
"id": "35121000",
"scheme": "CPV",
"description": "Security equipment"
},
{
"id": "35120000",
"scheme": "CPV",
"description": "Surveillance and security systems and devices"
},
{
"id": "35100000",
"scheme": "CPV",
"description": "Emergency and security equipment"
},
{
"id": "32324310",
"scheme": "CPV",
"description": "Satellite antennas"
},
{
"id": "34712200",
"scheme": "CPV",
"description": "Satellites"
},
{
"id": "45312000",
"scheme": "CPV",
"description": "Alarm system and antenna installation work"
},
{
"id": "79711000",
"scheme": "CPV",
"description": "Alarm-monitoring services"
},
{
"id": "35121700",
"scheme": "CPV",
"description": "Alarm systems"
}
]
},
{
"id": "15",
"relatedLot": "15",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "09330000",
"scheme": "CPV",
"description": "Solar energy"
},
{
"id": "71314300",
"scheme": "CPV",
"description": "Energy-efficiency consultancy services"
},
{
"id": "45261410",
"scheme": "CPV",
"description": "Roof insulation work"
},
{
"id": "45320000",
"scheme": "CPV",
"description": "Insulation work"
},
{
"id": "45321000",
"scheme": "CPV",
"description": "Thermal insulation work"
}
]
},
{
"id": "10",
"relatedLot": "10",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45442100",
"scheme": "CPV",
"description": "Painting work"
},
{
"id": "45442110",
"scheme": "CPV",
"description": "Painting work of buildings"
},
{
"id": "45442120",
"scheme": "CPV",
"description": "Painting and protective-coating work of structures"
},
{
"id": "45442121",
"scheme": "CPV",
"description": "Painting work of structures"
}
]
},
{
"id": "14",
"relatedLot": "14",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45111100",
"scheme": "CPV",
"description": "Demolition work"
},
{
"id": "45111000",
"scheme": "CPV",
"description": "Demolition, site preparation and clearance work"
},
{
"id": "45110000",
"scheme": "CPV",
"description": "Building demolition and wrecking work and earthmoving work"
}
]
},
{
"id": "11",
"relatedLot": "11",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "34953000",
"scheme": "CPV",
"description": "Access ramps"
}
]
},
{
"id": "13",
"relatedLot": "13",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "45110000",
"scheme": "CPV",
"description": "Building demolition and wrecking work and earthmoving work"
},
{
"id": "45111000",
"scheme": "CPV",
"description": "Demolition, site preparation and clearance work"
},
{
"id": "45111100",
"scheme": "CPV",
"description": "Demolition work"
}
]
},
{
"id": "12",
"relatedLot": "12",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "14712000",
"scheme": "CPV",
"description": "Lead"
},
{
"id": "45332200",
"scheme": "CPV",
"description": "Water plumbing work"
},
{
"id": "45332000",
"scheme": "CPV",
"description": "Plumbing and drain-laying work"
},
{
"id": "45111240",
"scheme": "CPV",
"description": "Ground-drainage work"
},
{
"id": "44163110",
"scheme": "CPV",
"description": "Drainage pipes"
},
{
"id": "90660000",
"scheme": "CPV",
"description": "Deleading services"
}
]
},
{
"id": "1",
"relatedLot": "1",
"deliveryLocation": {
"description": "Edinburgh"
},
"deliveryAddresses": [
{
"region": "UKM75"
}
],
"additionalClassifications": [
{
"id": "09300000",
"scheme": "CPV",
"description": "Electricity, heating, solar and nuclear energy"
},
{
"id": "31100000",
"scheme": "CPV",
"description": "Electric motors, generators and transformers"
},
{
"id": "45311000",
"scheme": "CPV",
"description": "Electrical wiring and fitting work"
},
{
"id": "45311100",
"scheme": "CPV",
"description": "Electrical wiring work"
},
{
"id": "38431200",
"scheme": "CPV",
"description": "Smoke-detection apparatus"
},
{
"id": "45310000",
"scheme": "CPV",
"description": "Electrical installation work"
},
{
"id": "45311200",
"scheme": "CPV",
"description": "Electrical fitting work"
},
{
"id": "45315000",
"scheme": "CPV",
"description": "Electrical installation work of heating and other electrical building-equipment"
},
{
"id": "45317000",
"scheme": "CPV",
"description": "Other electrical installation work"
},
{
"id": "45317300",
"scheme": "CPV",
"description": "Electrical installation work of electrical distribution apparatus"
},
{
"id": "71323100",
"scheme": "CPV",
"description": "Electrical power systems design services"
},
{
"id": "51110000",
"scheme": "CPV",
"description": "Installation services of electrical equipment"
}
]
}
],
"title": "Housing Property Capital Works Framework 2019 - 2023",
"status": "complete",
"legalBasis": {
"id": "32014L0024",
"scheme": "CELEX"
},
"techniques": {
"hasFrameworkAgreement": true
},
"description": "Housing Property Capital Works Framework 2019 - 2023\nchanged to 2020 to 2024",
"reviewDetails": "Precise information on deadline(s) for review procedures:\nA tenderer that suffers loss as a result of a breach of duty under the Public Contracts (Scotland) Regulations 2015 may bring proceedings in the Sheriff Court or the Court of Session. The City of Edinburgh Council (the Council) will have a minimum standstill period of 10 days before awarding the contract. The communication of the award decision notice will be sent by fax or e-mail to all tenderers with the standstill period commencing on the next day. If proceedings are started in the Sheriff Court or the Court of Session against the Council in respect of the decision to award the contract within the standstill period then the Council is prevented from awarding the contract. Post contract award the Sheriff Court or the Court of Session may (1) award damages provided proceedings are brought within 3 months from the date when the grounds for the bringing of the proceedings first arose (2) be entitled to issue an ineffectiveness order or impose a financial penalty on the Council. A claim for an ineffectiveness order must be made within 30 days of the Contract Award Notice being published in the OJEU or within 30 days of the date those who expressed an interest in or otherwise bid for the contract were informed of the conclusion of the contract or in any other case within 6 months from the date on which the contract was entered into.",
"classification": {
"id": "45210000",
"scheme": "CPV",
"description": "Building construction work"
},
"procurementMethod": "selective",
"mainProcurementCategory": "works",
"procurementMethodDetails": "Restricted procedure"
},
"parties": [
{
"id": "GB-FTS-346",
"name": "The City of Edinburgh Council",
"roles": [
"buyer"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH8 8BG",
"countryName": "United Kingdom",
"streetAddress": "Waverley Court, 4 East Market Street"
},
"details": {
"url": "http://www.edinburgh.gov.uk",
"buyerProfile": "https://www.publiccontractsscotland.gov.uk/search/Search_AuthProfile.aspx?ID=AA00290",
"classifications": [
{
"id": "REGIONAL_AUTHORITY",
"scheme": "TED_CA_TYPE",
"description": "Regional or local authority"
},
{
"id": "01",
"scheme": "COFOG",
"description": "General public services"
}
]
},
"identifier": {
"legalName": "The City of Edinburgh Council"
},
"contactPoint": {
"email": "lorna.lennen@edinburgh.gov.uk",
"telephone": "+44 1314693922"
}
},
{
"id": "GB-FTS-347",
"name": "Maclin Electric Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Musselburgh",
"postalCode": "EH21 7UL",
"countryName": "United Kingdom",
"streetAddress": "Block 2 Unit 3, Inveresk Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Maclin Electric Ltd"
},
"contactPoint": {
"faxNumber": "+44 1316532589",
"telephone": "+44 1316659991"
}
},
{
"id": "GB-FTS-348",
"name": "Morris & Spottiswood",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G51 3HQ",
"countryName": "United Kingdom",
"streetAddress": "54 Helen Street"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "Morris & Spottiswood"
},
"contactPoint": {
"telephone": "+44 01414254954"
}
},
{
"id": "GB-FTS-349",
"name": "Response Building Maintenance Services (Scotland) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM78",
"locality": "Livingston",
"postalCode": "EH54 8AS",
"countryName": "United Kingdom",
"streetAddress": "Caputhall Road, Deans Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Response Building Maintenance Services (Scotland) Ltd"
},
"contactPoint": {
"faxNumber": "+44 01506414181",
"telephone": "+44 01506411555"
}
},
{
"id": "GB-FTS-350",
"name": "Caltech Lifts Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Dundee",
"postalCode": "DD1 3NA",
"countryName": "United Kingdom",
"streetAddress": "Stannergate Road, Broughty Ferry"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Caltech Lifts Ltd"
},
"contactPoint": {
"telephone": "+44 07713981505"
}
},
{
"id": "GB-FTS-351",
"name": "T B Mackay Energy Services Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Edinburgh",
"postalCode": "EH5 1AB",
"countryName": "United Kingdom",
"streetAddress": "219 Granton Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "T B Mackay Energy Services Ltd"
},
"contactPoint": {
"faxNumber": "+44 01315593500",
"telephone": "+44 01315526103"
}
},
{
"id": "GB-FTS-352",
"name": "Easy Heat Systems Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Perth",
"postalCode": "PH1 3TS",
"countryName": "United Kingdom",
"streetAddress": "McDermott House Inveralmond Place, Inveralmond Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Easy Heat Systems Ltd"
},
"contactPoint": {
"telephone": "+44 01738445222"
}
},
{
"id": "GB-FTS-353",
"name": "Eden Group",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Edinburgh",
"postalCode": "EH17 7QJ",
"countryName": "United Kingdom",
"streetAddress": "43 Ellen's Glen Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Eden Group"
},
"contactPoint": {
"telephone": "+44 01316643906"
}
},
{
"id": "GB-FTS-354",
"name": "Firstcall Trade Services",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH14 1UT",
"countryName": "United Kingdom",
"streetAddress": "38 West Gorgie Parks, Edinburgh"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Firstcall Trade Services"
},
"contactPoint": {
"telephone": "+44 01312857150"
}
},
{
"id": "GB-FTS-355",
"name": "Maxi Construction Limited",
"roles": [
"supplier"
],
"address": {
"region": "UKM78",
"locality": "Livingston",
"postalCode": "EH54 5DJ",
"countryName": "United Kingdom",
"streetAddress": "Firth Road, Houstoun Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Maxi Construction Limited"
},
"contactPoint": {
"faxNumber": "+44 01506442010",
"telephone": "+44 01506442233"
}
},
{
"id": "GB-FTS-356",
"name": "JCJ Demolition and Construction Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Glasgow",
"postalCode": "G31 5es",
"countryName": "United Kingdom",
"streetAddress": "Nisbet Business Centre, 30 Nisbet St"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "JCJ Demolition and Construction Ltd"
},
"contactPoint": {
"faxNumber": "+44 01415543020",
"telephone": "+44 01415542758"
}
},
{
"id": "GB-FTS-357",
"name": "Ailsa Building Contractors Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Coatbridge",
"postalCode": "ML5 4AU",
"countryName": "United Kingdom",
"streetAddress": "251 Dundyvan Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Ailsa Building Contractors Ltd"
},
"contactPoint": {
"faxNumber": "+44 01236602623",
"telephone": "+44 01236422615"
}
},
{
"id": "GB-FTS-358",
"name": "Nicholson Bros (Electrical Contractors) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH9 1UH",
"countryName": "United Kingdom",
"streetAddress": "6A Grange Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Nicholson Bros (Electrical Contractors) Ltd"
},
"contactPoint": {
"faxNumber": "+44 1316624904",
"telephone": "+44 1316670281"
}
},
{
"id": "GB-FTS-359",
"name": "G D Chalmers Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Paisley",
"postalCode": "PA2 6ES",
"countryName": "United Kingdom",
"streetAddress": "101 Neilston Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "G D Chalmers Ltd"
},
"contactPoint": {
"telephone": "+44 01418896233"
}
},
{
"id": "GB-FTS-360",
"name": "OpenView Security Solutions Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Essex",
"postalCode": "RM7 7PJ",
"countryName": "United Kingdom",
"streetAddress": "OpenView House, Chesham Close, Romford"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "OpenView Security Solutions Ltd"
}
},
{
"id": "GB-FTS-361",
"name": "Belac Group Limited",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Bellshill",
"postalCode": "ML4 3PU",
"countryName": "United Kingdom",
"streetAddress": "Unit 3.4, 17 Starling Way, Western Campus"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Belac Group Limited"
},
"contactPoint": {
"telephone": "+44 1414590010"
}
},
{
"id": "GB-FTS-362",
"name": "Apex Developments Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Edinburgh",
"postalCode": "EH3 6LP",
"countryName": "United Kingdom",
"streetAddress": "8c Northumberland Street South East Lane"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Apex Developments Ltd"
},
"contactPoint": {
"telephone": "+44 01313164747"
}
},
{
"id": "GB-FTS-363",
"name": "Concrete Repairs ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM76",
"locality": "Falkirk",
"postalCode": "FK6 6QE",
"countryName": "United Kingdom",
"streetAddress": "Cathite House 31 Winchester Avenue, Denny"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Concrete Repairs ltd"
},
"contactPoint": {
"telephone": "+44 01324821400"
}
},
{
"id": "GB-FTS-364",
"name": "Insulated Render Systems (Scotland) Limited",
"roles": [
"supplier"
],
"address": {
"region": "UKM84",
"locality": "Airdrie",
"postalCode": "ML6 9AS",
"countryName": "United Kingdom",
"streetAddress": "74 Glencraig Street, Glencraig Street"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Insulated Render Systems (Scotland) Limited"
},
"contactPoint": {
"faxNumber": "+44 01236754995",
"telephone": "+44 01236754500"
}
},
{
"id": "GB-FTS-365",
"name": "Bell Decorating Group Limited",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Airdrie",
"postalCode": "ML6 9BG",
"countryName": "United Kingdom",
"streetAddress": "Bell Business Park, Rochsolloch Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Bell Decorating Group Limited"
},
"contactPoint": {
"telephone": "+44 01689837977"
}
},
{
"id": "GB-FTS-366",
"name": "Mears Group",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Gloucester",
"postalCode": "GL3 4AH",
"countryName": "United Kingdom",
"streetAddress": "1390 Montpellier Court, Gloucester Business Park, Brockworth,"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Mears Group"
}
},
{
"id": "GB-FTS-367",
"name": "Novus Property Solutions Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Bathgate",
"postalCode": "EH48 2EP",
"countryName": "United Kingdom",
"streetAddress": "3a Inchmuir Road, Whitehill Industrial Estate, Bathgate, West Lothian"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Novus Property Solutions Ltd"
},
"contactPoint": {
"faxNumber": "+44 01782598101",
"telephone": "+44 01782598000"
}
},
{
"id": "GB-FTS-368",
"name": "McTear Contracts Ltd.",
"roles": [
"supplier"
],
"address": {
"region": "UKM84",
"locality": "WISHAW",
"postalCode": "ML2 0EG",
"countryName": "United Kingdom",
"streetAddress": "12 Canyon Road , Wishaw"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "McTear Contracts Ltd."
},
"contactPoint": {
"telephone": "+44 07454689378"
}
},
{
"id": "GB-FTS-369",
"name": "Consult Lift Services Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Paisley",
"postalCode": "PA3 2RE",
"countryName": "United Kingdom",
"streetAddress": "Thistle House, Inchinnan Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Consult Lift Services Ltd"
},
"contactPoint": {
"telephone": "+44 07788209986"
}
},
{
"id": "GB-FTS-370",
"name": "Omega Lift Services LTD",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH17 8QF",
"countryName": "United Kingdom",
"streetAddress": "Unit B1, Gracemount Business Pavilions, Captains Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Omega Lift Services LTD"
},
"contactPoint": {
"telephone": "+44 07921477767"
}
},
{
"id": "GB-FTS-371",
"name": "JGM - John G Mackintosh",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH20 9LZ",
"countryName": "United Kingdom",
"streetAddress": "30 Dryden Road, Midlothian"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "JGM - John G Mackintosh"
},
"contactPoint": {
"faxNumber": "+44 01316681611",
"telephone": "+44 01316681168"
}
},
{
"id": "GB-FTS-372",
"name": "Everwarm Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM78",
"locality": "West Lothian",
"postalCode": "EH48 2EE",
"countryName": "United Kingdom",
"streetAddress": "3 Inchcorse Place, Whitehill Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Everwarm Ltd"
},
"contactPoint": {
"telephone": "+44 07584285520"
}
},
{
"id": "GB-FTS-373",
"name": "Gas Call Services Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM82",
"locality": "Glasgow",
"postalCode": "G33 4DB",
"countryName": "United Kingdom",
"streetAddress": "2 Queenslie Court, Summerlee Street"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Gas Call Services Ltd"
},
"contactPoint": {
"faxNumber": "+44 01417746881",
"telephone": "+44 01417663333"
}
},
{
"id": "GB-FTS-374",
"name": "Dalex Systems",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Roslin",
"postalCode": "EH25 9RE",
"countryName": "United Kingdom",
"streetAddress": "Midlothian Innovation Centre, Pentlandfield"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Dalex Systems"
},
"contactPoint": {
"faxNumber": "+44 01314409076",
"telephone": "+44 01314400945"
}
},
{
"id": "GB-FTS-375",
"name": "L&D Plumbing & Tiling Services Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G33 4DZ",
"countryName": "United Kingdom",
"streetAddress": "Units 2b&c, Burntbroom Court, Queenslie Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "L&D Plumbing & Tiling Services Ltd"
},
"contactPoint": {
"faxNumber": "+44 01417743003",
"telephone": "+44 01417743111"
}
},
{
"id": "GB-FTS-376",
"name": "North SV",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Braehead",
"postalCode": "PA4 8WF",
"countryName": "United Kingdom",
"streetAddress": "Titanium 1, Kings Inch Place, King's Inch Place, Braehead"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "North SV"
},
"contactPoint": {
"telephone": "+44 03338001111"
}
},
{
"id": "GB-FTS-377",
"name": "Trident Maintenance Services",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Coatbridge",
"postalCode": "ML5 3SP",
"countryName": "United Kingdom",
"streetAddress": "Unit 12, 33 Coatbank Street"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Trident Maintenance Services"
},
"contactPoint": {
"telephone": "+44 03302020774"
}
},
{
"id": "GB-FTS-378",
"name": "Mitie Property Services (UK) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G73 1AU",
"countryName": "United Kingdom",
"streetAddress": "35 Duchess Road"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "Mitie Property Services (UK) Ltd"
},
"contactPoint": {
"telephone": "+44 07545181948"
}
},
{
"id": "GB-FTS-379",
"name": "Dem-Master Demolition Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM78",
"locality": "Bathgate",
"postalCode": "EH48 2EN",
"countryName": "United Kingdom",
"streetAddress": "4 Pottishaw Place, Whitehill Ind Est"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Dem-Master Demolition Ltd"
},
"contactPoint": {
"telephone": "+44 01506654845"
}
},
{
"id": "GB-FTS-380",
"name": "Coleman & Company Limited",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "England",
"postalCode": "B44 9ER",
"countryName": "United Kingdom",
"streetAddress": "Shady Lane, Great Barr, Birmingham"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Coleman & Company Limited"
},
"contactPoint": {
"faxNumber": "+44 01213252425",
"telephone": "+44 01213252424"
}
},
{
"id": "GB-FTS-381",
"name": "Central Demolition Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Bonnybridge",
"postalCode": "FK4 2AG",
"countryName": "United Kingdom",
"streetAddress": "Central House, Chattan Industrial Estate, Bonnyside Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Central Demolition Ltd"
},
"contactPoint": {
"faxNumber": "+44 01324815922",
"telephone": "+44 01324815700"
}
},
{
"id": "GB-FTS-382",
"name": "Daltons Demolitions Limited",
"roles": [
"supplier"
],
"address": {
"region": "UKM73",
"locality": "Edinburgh",
"postalCode": "EH12 9BU",
"countryName": "United Kingdom",
"streetAddress": "Gogarbank Iron & Steelworks, Station Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Daltons Demolitions Limited"
},
"contactPoint": {
"faxNumber": "+44 01313177168",
"telephone": "+44 01313395355"
}
},
{
"id": "GB-FTS-383",
"name": "P1 Solutions Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Edinburgh",
"postalCode": "EH6 7JQ",
"countryName": "United Kingdom",
"streetAddress": "7 Links Gardens Lane"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "P1 Solutions Ltd"
},
"contactPoint": {
"faxNumber": "+44 01315533103",
"telephone": "+44 01315554968"
}
},
{
"id": "GB-FTS-384",
"name": "Glendale Grounds Management Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKD47",
"locality": "Chorley",
"postalCode": "PR74AT",
"countryName": "United Kingdom",
"streetAddress": "The Stables, , Duxbury Hall Road, Duxbury Park,"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Glendale Grounds Management Ltd"
},
"contactPoint": {
"telephone": "+44 01257460461"
}
},
{
"id": "GB-FTS-385",
"name": "Mackenzie Construction Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G46 7TL",
"countryName": "United Kingdom",
"streetAddress": "Burnfield Avenue , Thornliebank"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Mackenzie Construction Ltd"
},
"contactPoint": {
"faxNumber": "+44 01416335656",
"telephone": "+44 01416335555"
}
},
{
"id": "GB-FTS-386",
"name": "J Sives Surfacing Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM75",
"locality": "Edinburgh",
"postalCode": "EH9 3DP",
"countryName": "United Kingdom",
"streetAddress": "91b West Savile Terrace"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "J Sives Surfacing Ltd"
},
"contactPoint": {
"faxNumber": "+44 01316620411",
"telephone": "+44 01316683070"
}
},
{
"id": "GB-FTS-387",
"name": "Thomas Menzies (Builders) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Kirkcaldy",
"postalCode": "KY2 5DH",
"countryName": "United Kingdom",
"streetAddress": "Hayfield Place, Hayfield Industrial Estate"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Thomas Menzies (Builders) Ltd"
},
"contactPoint": {
"faxNumber": "+44 015292200498",
"telephone": "+44 01592264712"
}
},
{
"id": "GB-FTS-388",
"name": "Hillhouse Quarry Group Ltd T/A MacASPHALT",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Paisley",
"postalCode": "PA2 7AN",
"countryName": "United Kingdom",
"streetAddress": "25 Scotts Road"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "Hillhouse Quarry Group Ltd T/A MacASPHALT"
},
"contactPoint": {
"telephone": "+44 01418879109"
}
},
{
"id": "GB-FTS-389",
"name": "A.C. Whyte & Co. Ltd.",
"roles": [
"supplier"
],
"address": {
"region": "UKM",
"locality": "Glasgow",
"postalCode": "G78 1BF",
"countryName": "United Kingdom",
"streetAddress": "A C Whyte & Co, 6 Bowerwalls Place, Barrhead"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "A.C. Whyte & Co. Ltd."
},
"contactPoint": {
"faxNumber": "+44 01418806582",
"telephone": "+44 01418819519"
}
},
{
"id": "GB-FTS-390",
"name": "Procast Building Contractors Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM95",
"locality": "Strathaven",
"postalCode": "ML10 6LT",
"countryName": "United Kingdom",
"streetAddress": "31 Green Street"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "Procast Building Contractors Ltd"
},
"contactPoint": {
"telephone": "+44 07799862737"
}
},
{
"id": "GB-FTS-391",
"name": "MP Group UK Limited",
"roles": [
"supplier"
],
"address": {
"region": "UK",
"locality": "Glasgow",
"postalCode": "G51 4DX",
"countryName": "United Kingdom",
"streetAddress": "324 Drumoyne Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "MP Group UK Limited"
},
"contactPoint": {
"telephone": "+44 01412371970"
}
},
{
"id": "GB-FTS-392",
"name": "SERS Energy Solutions (Scotland) Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKM73",
"locality": "Livingston",
"postalCode": "EH54 6TS",
"countryName": "United Kingdom",
"streetAddress": "12 Fairbairn Road"
},
"details": {
"scale": "sme"
},
"identifier": {
"legalName": "SERS Energy Solutions (Scotland) Ltd"
},
"contactPoint": {
"telephone": "+44 07917758787"
}
},
{
"id": "GB-FTS-393",
"name": "Edinburgh Sheriff Court",
"roles": [
"reviewBody"
],
"address": {
"locality": "Edinburgh",
"countryName": "United Kingdom",
"streetAddress": "Chalmers Street"
},
"details": {
"url": "http://www.edinburgh.gov.uk"
},
"identifier": {
"legalName": "Edinburgh Sheriff Court"
}
},
{
"id": "GB-FTS-394",
"name": "The City of Edinburgh Council",
"roles": [
"reviewContactPoint"
],
"address": {
"locality": "Edinburgh",
"postalCode": "EH8 8BG",
"countryName": "United Kingdom",
"streetAddress": "4 East Market Street"
},
"identifier": {
"legalName": "The City of Edinburgh Council"
}
}
],
"language": "en",
"contracts": [
{
"id": "000136-2021-1",
"title": "Electrical Works Supply and/or Install",
"value": {
"amount": 9000000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-1",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-2",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works Less than 500,000 GBP.",
"value": {
"amount": 9600000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-2",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-3",
"title": "Kitchen and Bathroom, Supply and/or Install",
"value": {
"amount": 36000000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-3",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-4",
"title": "Lift Replacement, Refurbishment and Upgrading Works - Supply and/or Install",
"value": {
"amount": 4800000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-4",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-5",
"title": "Mechanical Installations and Upgrading Works - Supply and/or Install",
"value": {
"amount": 7200000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-5",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-6",
"title": "Domestic Gas and Plumbing Installations, Supply and or Install",
"value": {
"amount": 9600000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-6",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-7",
"title": "Security - Door and Alarm Systems",
"value": {
"amount": 7200000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-7",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-8",
"title": "Painting, Decorating and Associated Preparation Works Internal and External",
"value": {
"amount": 960000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-8",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-9",
"title": "Adaptations - Ramp Installations",
"value": {
"amount": 5760000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-9",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-10",
"title": "Lead Replacement, Distribution Pipework Removal and Replacement",
"value": {
"amount": 2400000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-10",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-11",
"title": "Demolition City Wide - less than 250k GBP",
"value": {
"amount": 3600000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-11",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-12",
"title": "External Works – Neighbourhood Environmental Projects (NEPs)",
"value": {
"amount": 10080000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-12",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-13",
"title": "Demolition City Wide - less than 250k GBP",
"value": {
"amount": 2400000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-13",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-14",
"title": "Energy Efficiency",
"value": {
"amount": 30000000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-14",
"dateSigned": "2020-11-30T00:00:00Z"
},
{
"id": "000136-2021-15",
"title": "Multi Trade Works incl: Fabric Repairs & Improvements, Works greater than 500,000 GBP",
"value": {
"amount": 60000000,
"currency": "GBP"
},
"status": "active",
"awardID": "000136-2021-15",
"dateSigned": "2020-11-30T00:00:00Z"
}
],
"description": "This Framework will now run from 2020 to 2024 (inclusive of discretionary extension options).\n(SC Ref:638636)",
"initiationType": "tender"
}