Giles Lane Student Accommodation Project

{
  "id": "017726-2024",
  "tag": [
    "award",
    "contract"
  ],
  "bids": {
    "statistics": [
      {
        "id": "1",
        "value": 1,
        "measure": "bids",
        "relatedLot": "1"
      }
    ]
  },
  "date": "2024-06-07T13:39:33+01:00",
  "ocid": "ocds-h6vhtk-044e95",
  "buyer": {
    "id": "GB-COH-RC000656",
    "name": "UNIVERSITY OF KENT"
  },
  "awards": [
    {
      "id": "017726-2024-1",
      "status": "active",
      "suppliers": [
        {
          "id": "GB-COH-12093126",
          "name": "Giles Lane Investments Limited"
        }
      ],
      "relatedLots": [
        "1"
      ]
    }
  ],
  "tender": {
    "id": "ocds-h6vhtk-044e95",
    "lots": [
      {
        "id": "1",
        "status": "cancelled",
        "hasOptions": false,
        "description": "This Notice sets out the contracting authority's award of a works contract using the negotiated procedure without prior publication, in accordance with Regulation 32 of the Public Contracts Regulations 2015.The University of Kent (the \"University\") has entered into a transaction to secure new student accommodation (\"the Transaction\"). The University has entered into an Agreement for Lease (\"AFL\") with Canada Life (the \"Fund\") and Giles Lane Investments Limited (the \"Developer\") for the construction of 91 new student rooms (the \"Development\") on a property known as Landon, Giles Lane (\"Landon\") which adjoins the University's Canterbury campus.\nThe AFL contains obligations on the Developer to procure the construction of the Development and obligations on the Fund to grant an occupational lease to the University (\"the Underlease\") on practical completion of the Development. The Underlease will be a full repairing and insuring, financing lease, with limited rights of assignment by the University, containing an indexing rent with cap and collar. On expiry of the Underlease, subject to payment of all rents and interest to the Fund, the University will have the option to purchase the Headlease from the Fund for one pound (£1) (the Fund will also have the option to require the University to purchase the Headlease for one pound (£1)).\nThe Transaction comprises a number of other arrangements, including:\n• a building contract between the Developer and a building contractor, and the appointments of a professional team by the Developer, with warranties in favour of the University;\n• arrangements in respect of the construction and maintenance of a wetland, to satisfy a planning condition for the Development;\n• licence arrangements to enable certain other wetland works to be undertaken on the University's campus, to satisfy a planning condition for the Development;\n• the grant to the Developer of an option over other land of the University; \n• the University received a payment on completion of the Transaction.",
        "awardCriteria": {
          "criteria": [
            {
              "type": "price"
            }
          ]
        }
      }
    ],
    "items": [
      {
        "id": "1",
        "relatedLot": "1",
        "deliveryAddresses": [
          {
            "region": "UKJ4"
          }
        ],
        "additionalClassifications": [
          {
            "id": "45000000",
            "scheme": "CPV",
            "description": "Construction work"
          }
        ]
      }
    ],
    "title": "Giles Lane Student Accommodation Project",
    "status": "complete",
    "coveredBy": [
      "GPA"
    ],
    "legalBasis": {
      "id": "32014L0024",
      "scheme": "CELEX"
    },
    "description": "A Public Works contract under Regulation 32(2) (b) (iii) of the Public Contract Regulations 2015 for the development of student accommodation at Giles Lane, Canterbury, Kent.",
    "classification": {
      "id": "45000000",
      "scheme": "CPV",
      "description": "Construction work"
    },
    "procurementMethod": "limited",
    "mainProcurementCategory": "works",
    "procurementMethodDetails": "Award procedure without prior publication of a call for competition",
    "procurementMethodRationale": "Negotiated Procedure without prior publication (Regulation 32(2)(b)(iii) Public Contracts Regulations 2015, as amended).\nExplanation:\nThe University in good faith considers that the award of the contract without prior publication of a contract notice is permitted by Part 2 of the Public Contracts Regulations 2015 (as amended). \nThe University's justification for this view is that, in good faith, it considers that the works to be delivered under the contract can only be provided by a particular economic operator (i.e. the Developer) for the following reason: protection of exclusive rights under Regulation 32(2)(b)(iii) of the Public Contracts Regulations 2015. \nThe University considers that:\n•\tthe University requires new student accommodation urgently to meet its growing student demand and the Development is capable of being delivered in time for the September 2025 intake of students;\n•\tthe University's students demand \"on campus\" accommodation and Landon is ideally located on a site which adjoins, and can be incorporated into, the University's campus; \n•\tthe Developer holds exclusive rights to acquire Landon under the Option;\n•\tthe Developer's exclusive rights include;\no\tthe Developer's rights in respect of Landon, pursuant to the Option; \no\tthe fact that Landon adjoins the University's Canterbury campus; \no\tthe Developer has secured planning permission for the Development;\no\tthe Developer owns the intellectual property in the design for which planning permission has been obtained; \no\tthe Developer has negotiated terms with a third party, to deliver a wetland on third party land, which wetland is required to satisfy a condition in the relevant planning permission;\no\tthe Developer has negotiated terms with a funder and contractor, such that the Developer will commit (in the AFL) to delivering the Development in time for September 2025;\n•\tthis opportunity for the Development and the Transaction exists solely as a result of those rights;\n•\tthe absence of competition is not a result of artificial narrowing down of the parameters of the procurement by the University;\n•\tno reasonable alternative or substitute exists for the delivery of so many rooms \"on campus\" in time for September 2025; and \n•\tthere is no reasonable alternative route to acquire Landon for development without it being a condition under the Transaction for the Developer to be the supplier appointed to undertake any development works.",
    "procurementMethodRationaleClassifications": [
      {
        "id": "D_PROTECT_RIGHTS",
        "scheme": "TED_PT_AWARD_CONTRACT_WITHOUT_CALL",
        "description": "The works, supplies or services can be provided only by a particular economic operator due to protection of exclusive rights, including intellectual property rights"
      }
    ]
  },
  "parties": [
    {
      "id": "GB-COH-RC000656",
      "name": "UNIVERSITY OF KENT",
      "roles": [
        "buyer"
      ],
      "address": {
        "region": "UKJ4",
        "locality": "Canterbury",
        "postalCode": "CT2 7NZ",
        "countryName": "United Kingdom",
        "streetAddress": "The Registry"
      },
      "details": {
        "url": "https://www.kent.ac.uk/",
        "classifications": [
          {
            "id": "BODY_PUBLIC",
            "scheme": "TED_CA_TYPE",
            "description": "Body governed by public law"
          },
          {
            "id": "09",
            "scheme": "COFOG",
            "description": "Education"
          }
        ]
      },
      "identifier": {
        "id": "RC000656",
        "scheme": "GB-COH",
        "legalName": "UNIVERSITY OF KENT"
      },
      "contactPoint": {
        "name": "Mark Reed",
        "email": "m.reed@kent.ac.uk",
        "telephone": "+44 1227824301"
      }
    },
    {
      "id": "GB-COH-12093126",
      "name": "Giles Lane Investments Limited",
      "roles": [
        "supplier"
      ],
      "address": {
        "region": "UKJ",
        "locality": "Hythe",
        "postalCode": "CT21 5LB",
        "countryName": "United Kingdom",
        "streetAddress": "134 High Street"
      },
      "details": {
        "scale": "large"
      },
      "identifier": {
        "id": "12093126",
        "scheme": "GB-COH",
        "legalName": "Giles Lane Investments Limited"
      }
    },
    {
      "id": "GB-FTS-100077",
      "name": "High Court of England of Wales",
      "roles": [
        "reviewBody"
      ],
      "address": {
        "locality": "London",
        "postalCode": "WC2A 2LL",
        "countryName": "United Kingdom",
        "streetAddress": "Royal Courts of Justice, The Strand"
      },
      "identifier": {
        "legalName": "High Court of England of Wales"
      }
    }
  ],
  "language": "en",
  "contracts": [
    {
      "id": "017726-2024-1",
      "value": {
        "amount": 51000000,
        "currency": "GBP"
      },
      "status": "active",
      "awardID": "017726-2024-1",
      "dateSigned": "2024-05-09T00:00:00+01:00"
    }
  ],
  "initiationType": "tender"
}

{
  "id": "010427-2024",
  "tag": [
    "award",
    "contract"
  ],
  "date": "2024-03-28T17:16:12Z",
  "ocid": "ocds-h6vhtk-044e95",
  "buyer": {
    "id": "GB-COH-RC000656",
    "name": "UNIVERSITY OF KENT"
  },
  "awards": [
    {
      "id": "010427-2024-1",
      "status": "active",
      "suppliers": [
        {
          "id": "GB-COH-12093126",
          "name": "Giles Lane Investments Limited"
        }
      ],
      "relatedLots": [
        "1"
      ]
    }
  ],
  "tender": {
    "id": "ocds-h6vhtk-044e95",
    "lots": [
      {
        "id": "1",
        "hasOptions": false,
        "description": "This Notice sets out the contracting authority's intention to award a works contract using the negotiated procedure without prior publication, in accordance with Regulation 32 of the Public Contracts Regulations 2015.\nThe University of Kent (the \"University\") intends to enter into a transaction to secure new student accommodation (\"the Transaction\"). The University will enter into an Agreement for Lease (\"AFL\") with Canada Life (the \"Fund\") and Giles Lane Investments Limited (the \"Developer\") for the construction of 91 new student rooms (the \"Development\") on a property known as Landon, Giles Lane (\"Landon\") which adjoins the University's Canterbury campus.\nThe Developer has the option to purchase Landon from the current owners (the \"Option\") and has obtained planning permission for the Development. The AFL will contain obligations on the Developer to procure the construction of the Development and obligations on the Fund to grant an occupational lease to the University (\"the Underlease\") on practical completion of the Development. The Underlease will be a full repairing and insuring, financing lease, with limited rights of assignment by the University, containing an indexing rent with cap and collar. On expiry of the Underlease, subject to payment of all rents and interest to the Fund, the University will have the option to purchase the Headlease from the Fund for one pound (£1) (the Fund will also have the option to require the University to purchase the Headlease for one pound (£1)).\nThe Transaction comprises a number of other arrangements, including: \n•\ta building contract between the Developer and a building contractor, and the appointments of a professional team by the Developer, with warranties in favour of the University;\n•\tarrangements in respect of the construction and maintenance of the wetland, which is described in section IV.1.1;\n•\tlicence arrangements to enable the Developer to locate contractor welfare facilities and store other materials on the University's campus;\n•\tlicence arrangements to enable certain other wetland works to be undertaken on the University's campus, to satisfy a planning condition for the Development;\n•\tthe Developer has an option over other land of the University which, together with Landon and other parcels of land in third party ownership, was intended to comprise one large development of student accommodation, which option over the said University land is to be varied now that Landon will progress independently;\n•\tthe University will receive a payment on completion of the Transaction.\nThe works can only be provided by the Developer for the following reason: protection of exclusive rights under Regulation 32 (2) (b) (iii) of the Public Contracts Regulations 2015."
      }
    ],
    "items": [
      {
        "id": "1",
        "relatedLot": "1",
        "deliveryLocation": {
          "description": "Canterbury, Kent"
        },
        "deliveryAddresses": [
          {
            "region": "UKJ"
          }
        ],
        "additionalClassifications": [
          {
            "id": "45000000",
            "scheme": "CPV",
            "description": "Construction work"
          }
        ]
      }
    ],
    "title": "Giles Lane Student Accommodation Project",
    "status": "complete",
    "legalBasis": {
      "id": "32014L0024",
      "scheme": "CELEX"
    },
    "description": "Intention to award a Public Works contract under Regulation 32(2) (b) (iii) of the Public Contract Regulations 2015 for the development of student accommodation at Giles Lane, Canterbury, Kent. The Negotiated Procedure without Prior Publication is being followed and is justified under Regulation 32 (2) (b) (iii).",
    "classification": {
      "id": "45000000",
      "scheme": "CPV",
      "description": "Construction work"
    },
    "procurementMethod": "limited",
    "mainProcurementCategory": "works",
    "procurementMethodDetails": "Award procedure without prior publication of a call for competition",
    "procurementMethodRationale": "Negotiated Procedure without prior publication (Regulation 32(2)(b)(iii) Public Contracts Regulations 2015, as amended).\nExplanation:\nThe University in good faith considers that the award of the contract without prior publication of a contract notice is permitted by Part 2 of the Public Contracts Regulations 2015 (as amended). \nThe University's justification for this view is that, in good faith, it considers that the works to be delivered under the contract can only be provided by a particular economic operator (i.e. the Developer) for the following reason: protection of exclusive rights under Regulation 32(2)(b)(iii) of the Public Contracts Regulations 2015. \nThe University considers that:\n•\tthe University requires new student accommodation urgently to meet its growing student demand and the Development is capable of being delivered in time for the September 2025 intake of students;\n•\tthe University's students demand \"on campus\" accommodation and Landon is ideally located on a site which adjoins, and can be incorporated into, the University's campus; \n•\tthe Developer holds exclusive rights to acquire Landon under the Option;\n•\tthe Developer's exclusive rights include;\no\tthe Developer's rights in respect of Landon, pursuant to the Option; \no\tthe fact that Landon adjoins the University's Canterbury campus; \no\tthe Developer has secured planning permission for the Development;\no\tthe Developer owns the intellectual property in the design for which planning permission has been obtained; \no\tthe Developer has negotiated terms with a third party, to deliver a wetland on third party land, which wetland is required to satisfy a condition in the relevant planning permission;\no\tthe Developer has negotiated terms with a funder and contractor, such that the Developer will commit (in the AFL) to delivering the Development in time for September 2025;\n•\tthis opportunity for the Development and the Transaction exists solely as a result of those rights;\n•\tthe absence of competition is not a result of artificial narrowing down of the parameters of the procurement by the University;\n•\tno reasonable alternative or substitute exists for the delivery of so many rooms \"on campus\" in time for September 2025; and \n•\tthere is no reasonable alternative route to acquire Landon for development without it being a condition under the Transaction for the Developer to be the supplier appointed to undertake any development works.\nThis VEAT notice demonstrates the intention to award a public works contract using the Negotiated Procedure without prior publication (Regulation 32(2)(b)(iii) Public Contracts Regulations 2015, as amended). \nThis contract has not yet been entered into and a contract award notice will be published following award.",
    "procurementMethodRationaleClassifications": [
      {
        "id": "D_OUTSIDE_SCOPE",
        "scheme": "TED_PT_AWARD_CONTRACT_WITHOUT_CALL",
        "description": "The procurement falls outside the scope of application of the directive"
      }
    ]
  },
  "parties": [
    {
      "id": "GB-COH-RC000656",
      "name": "UNIVERSITY OF KENT",
      "roles": [
        "buyer"
      ],
      "address": {
        "region": "UKJ4",
        "locality": "Canterbury",
        "postalCode": "CT2 7NZ",
        "countryName": "United Kingdom",
        "streetAddress": "The University of Kent  The Registry,"
      },
      "details": {
        "url": "https://www.kent.ac.uk/",
        "classifications": [
          {
            "id": "BODY_PUBLIC",
            "scheme": "TED_CA_TYPE",
            "description": "Body governed by public law"
          },
          {
            "id": "09",
            "scheme": "COFOG",
            "description": "Education"
          }
        ]
      },
      "identifier": {
        "id": "RC000656",
        "scheme": "GB-COH",
        "legalName": "UNIVERSITY OF KENT"
      },
      "contactPoint": {
        "name": "Mark Reed",
        "email": "m.reed@kent.ac.uk",
        "telephone": "+44 1227824301"
      }
    },
    {
      "id": "GB-COH-12093126",
      "name": "Giles Lane Investments Limited",
      "roles": [
        "supplier"
      ],
      "address": {
        "region": "UKJ",
        "locality": "Hythe",
        "postalCode": "CT21 5LB",
        "countryName": "United Kingdom",
        "streetAddress": "134 High Street,"
      },
      "details": {
        "scale": "large"
      },
      "identifier": {
        "id": "12093126",
        "scheme": "GB-COH",
        "legalName": "Giles Lane Investments Limited"
      }
    },
    {
      "id": "GB-FTS-100077",
      "name": "High Court of England of Wales",
      "roles": [
        "reviewBody"
      ],
      "address": {
        "locality": "London",
        "postalCode": "WC2A 2LL",
        "countryName": "United Kingdom",
        "streetAddress": "Royal Courts of Justice, The Strand"
      },
      "identifier": {
        "legalName": "High Court of England of Wales"
      }
    }
  ],
  "language": "en",
  "contracts": [
    {
      "id": "010427-2024-1",
      "value": {
        "amount": 51000000,
        "currency": "GBP"
      },
      "status": "active",
      "awardID": "010427-2024-1",
      "dateSigned": "2024-03-28T00:00:00Z"
    }
  ],
  "description": "Total value of the contract/lot/concession:\n£51,000,000 (Note: the total value of the contract noted here is the aggregate of the rent payable by the University under the Underlease (as defined in Section II.2.4) but, whereas this figure assumes 0% inflation, in practice the rent will be subject to indexation.)",
  "initiationType": "tender"
}