Find a TenderAwardedContract award notice
Published 5 Aug 2025, 10:39 BST

Official UK procurement notice

Invitation to Tender (ITT) - Construction & Capital Works

Official notice

Authority: Crescent Purchasing Consortium Limited (Public body)

45 lotsWorksCompetitive flexible procedureAbove thresholdSME suitableVCSE suitable
Published estimate£9,500,000,000total for 45 lots · £11,400,000,000 inc. VAT · 1 value update
Submissions closed 30 Oct 2025awarded 3 Jun 2026
Awarded to Aptus Construction Ltd +30 more15 awards
Contract term 2 yrsends 30 Apr 2028 · up to 30 Apr 2034 with extensions · starts 1 May 2026

What is being bought45 lots · detail below

Published requirement description

The Framework will provide fully compliant, flexible and streamlined access to pre-qualified construction partners for the delivery of capital works projects across the education and wider public sectors throughout the UK. It will support a broad range of new-build construction and refurbishment schemes from schools, colleges and universities to healthcare and civic infrastructure using a variety of standard forms of contract (including JCT and NEC) to suit employer preference. The Framework is designed to reduce procurement burden at call-off, enable regional and project specific delivery through a lotting structure, and ensure alignment with the Procurement Act 2023, National Procurement Policy Statement (NPPS), the Construction Playbook and Gold Standard principles.

  • How the procedure runs: This procurement will be conducted using a Competitive Flexible Procedure in accordance with Section 20 of the Procurement Act 2023. The procedure has been designed to ensure compliance with the Act while providing the Contracting Authority with the flexibility required to structure a process proportionate to the subject matter and complexity of this procurement. The process will comprise multiple stages: 1. Selection Stage: Bidders will be assessed to determine whether they are excluded or excludable suppliers under the Act and whether they meet the stated conditions of participation. Following evaluation, only the ten (10) highest scoring compliant bidders per Lot will be invited to progress to the next stage. 2. Dialogue Phase: Shortlisted suppliers will be invited to engage in structured dialogue to refine aspects of the procurement, including the approach to call-off contracts (based on the NEC and JCT suites), the framework conditions and the framework fee structure. 3. Final Tender Stage: Following dialogue, the Contracting Authority may issue clarifications or amendments to the procurement documents. Bidders will then be invited to submit final tenders, which will be evaluated against published qualitative and commercial criteria. 4. Award: Contracts will be awarded to the most advantageous tenders, in accordance with Section 19 of the Procurement Act 2023. This bespoke procedure is designed to balance full compliance with the Procurement Act 2023 with a streamlined, transparent, and fair process that secures the best outcomes for both Contracting Authorities and framework suppliers.

CPV: Construction work

Lots and requirements (45)Procurement structure

25 of 45 loaded on this page

Showing the first 25 of 45 published lots; the full list is in the JSON and Markdown mirrors of this notice. 45 lots · all with a published value (£5,277,777,778 together) · same conditions of participation on every lot · same evaluation weights on every lot.

Lot #1(a) - England (North) - JCT Minor Works Building Contract (MW)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #2(b) - England (North) - JCT Intermediate Building Contract (IC)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #3(c)– England (North) – JCT Design and Build Contract (D&B)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #4(d) – England North – JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #5(e) – England North – NEC 4 Engineering and Construction Short ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #6(f) – England North – NEC4 Engineering and Construction ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #7(g) – England North - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #8(h) – England North - NEC4 Engineering and Construction Contract with D&BAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #9(i) – England North - National Federation of Demolition Contractors Direct Form of ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #10(a) – England Midlands - JCT Minor Works Building Contract (MW)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #11(b) - England Midlands- JCT Intermediate Building Contract (IC)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #12(c) - England Midlands- JCT Design and Build Contract (D&B)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #13(d) – England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #14(e) - England Midlands - NEC 4 Engineering and Construction Short ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #15(f) – England Midlands - NEC4 Engineering and Construction ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #16(g) – England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #17(h) – England Midlands - NEC4 Engineering and Construction Contract with D&BAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #18(i) – England Midlands - National Federation of Demolition Contractors Direct Form of ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #19(a) – England South - JCT Minor Works Building Contract (MW)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #20(b) – England South - JCT Intermediate Building Contract (IC)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #21(c) - England South - JCT Design and Build Contract (D&B)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #22(d) – England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)AwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #23(e) - England South - NEC 4 Engineering and Construction Short ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #24(f) – England South - NEC4 Engineering and Construction ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

Lot #25(g) – England South - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractAwardedRenewal 2 yrsSMEVCSEPublished value£211,111,111

The source published no individual description for this lot.

Contract period: 1 May 2026 – 30 Apr 2028 (2 yrs) · up to 30 Apr 2034 with extensionsValue: £211,111,111 exc. VAT · £253,333,333 inc. VAT
Delivery: UKEligibility: SME eligibleVCSE eligible
Extensions: Maximum 3 extensions of 24 months per extension.
Pre-qualification & selection criteria (PQQ)2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

What it takes to win
i

How this buyer will score bids.

The evaluation criteria and weights exactly as published on the notice, grouped by family (price, quality, social value and so on).

Evaluation split and conditions of participation as published; the tender pack may add more
How bids were scored · same split on all 45 lots
Quality: 70%Price: 30%
Published sub-criteria (2)
  • Customer Requirements: 70%
  • Pricing: 30%
Published award criteria (2)
  • Pricing
  • Customer Requirements
Conditions of participation · identical on every lot2
  • Economic & financial standing

    Confirmed in document pack

  • Technical & professional ability

    Confirmed in document pack

What this means for your bid
  • Price carries 30 of 100 points: a 10% discount moves about 3 points. The method statement decides this lot, not the discount.

Price arithmetic assumes straight proportional scoring; the tender pack may use another formula.

Procedure terms & legal framework

From the official record
Procedure method
Competitive flexible procedure
Legal basis
UKPGA · 2023/54 Procurement Act 2023
Procurement category
Works
Notice status
Awarded
Procurement threshold
Above threshold (FTS publication)
Regulatory regime
Standard
Commercial structure
Stand-alone contract (no framework)
Competition type
Competitive procedure
GPA / WTO covered
Unspecified in notice
Recurring procurement
Unspecified in notice
First published
5 Aug 2025, 10:39 BST
Last source update
25 Jun 2026, 10:18 BST
Award evaluation window
Submission end – 1 May 2026
Authority reference
CA16292
FTS notice number
2025/S 000-062263
Latest notice
Contract award notice (UK6)
Classification (CPV)
Construction work
Delivery area
UK
Official registry OCID
ocds-h6vhtk-058142 Find a Tender
How it runs

This procurement will be conducted using a Competitive Flexible Procedure in accordance with Section 20 of the Procurement Act 2023. The procedure has been designed to ensure compliance with the Act while providing the Contracting Authority with the flexibility required to structure a process proportionate to the subject matter and complexity of this procurement.

The process will comprise multiple stages:

  1. Selection Stage: Bidders will be assessed to determine whether they are excluded or excludable suppliers under the Act and whether they meet the stated conditions of participation. Following evaluation, only the ten (10) highest scoring compliant bidders per Lot will be invited to progress to the next stage.
  2. Dialogue Phase: Shortlisted suppliers will be invited to engage in structured dialogue to refine aspects of the procurement, including the approach to call-off contracts (based on the NEC and JCT suites), the framework conditions and the framework fee structure.
  3. Final Tender Stage: Following dialogue, the Contracting Authority may issue clarifications or amendments to the procurement documents. Bidders will then be invited to submit final tenders, which will be evaluated against published qualitative and commercial criteria.
  4. Award: Contracts will be awarded to the most advantageous tenders, in accordance with Section 19 of the Procurement Act 2023.

This bespoke procedure is designed to balance full compliance with the Procurement Act 2023 with a streamlined, transparent, and fair process that secures the best outcomes for both Contracting Authorities and framework suppliers.

How it was run

Official notice
Run through: MultiQuote · Who buys & how to bid on MultiQuote
Supplier login requiredElectronic submission allowedLanguage: EN
Access & registration note: Free
Submission deadline
30 Oct 2025, 17:00 GMT
Clarification deadline
27 Oct 2025, 17:00 GMT
Submission channel
Official e-sourcing portal
Electronic submission
Allowed
Accepted languages
en
Detailed submission instructions & authority contactsFrom official release

To access this opportunity, log in to suppliers.multiquote.com ↗ and view the opportunity. If you are not registered with MultiQuote, please visit suppliers.multiquote.com ↗, complete the registration form on the log in page and quote the title and reference of the notice in your registration.

Timeline

5 Aug 2025 → 25 Jun 2026 · 10 dates
  1. Planning notice published
    5 Aug 2025, 10:39 BST
  2. Market engagement
    30 Aug 2025, 23:59 BST

    Engagement

  3. Next notice expected391 days ago
    25 Sept 2025, 23:59 BST
  4. Tender notice published384 days ago
    3 Oct 2025, 15:45 BST
  5. Clarification questions by360 days ago
    27 Oct 2025, 17:00 GMT
  6. Submission deadline357 days ago
    30 Oct 2025, 17:00 GMT
  7. Contract starts174 days ago
    1 May 2026, 00:00 BST
  8. Award decision expected by173 days ago
    1 May 2026, 23:59 BST
  9. Assessment summaries sent141 days ago
    3 Jun 2026, 00:00 BST
  10. Latest notice published119 days ago
    25 Jun 2026, 10:18 BST

Notice history

11 events · 5 releases on Find a Tender · since 5 Aug 2025
  1. First planning notice published
    5 Aug 2025, 10:39 BST
  2. Published value updated to £9,500,000,000
    3 Oct 2025, 15:45 BST
    was £0
  3. Status changed to active
    3 Oct 2025, 15:45 BST
  4. Procurement method changed
    3 Oct 2025, 15:45 BST
  5. Deadline published: 30 Oct 2025, 17:00 GMT
    3 Oct 2025, 15:45 BST
  6. First tender notice published
    3 Oct 2025, 15:45 BST
  7. Status changed to complete
    12 Jun 2026, 15:42 BST
  8. Procurement method changed
    12 Jun 2026, 15:42 BST
  9. First award notice published
    12 Jun 2026, 15:42 BST
  10. Contract award notice published
    25 Jun 2026, 10:18 BST
    UK6
  11. Contract signature expected
    30 Jun 2026, 23:59 BST
    scheduled
Routine re-releases (5)
  • 2025-10: 1 release · 3 Oct 2025
  • 2025-08: 1 release · 5 Aug 2025

Commercial outcome & contract awards

Published awards, contracts and bid statistics, not a forecast
Awards 45
Awarded value £3,166,666,65815 awards exc. VAT
Bids received 24135 from SMEs
Named bidders 50published on the award notice
Awarded toValueDateStatus
Lot 1 · (a) - England (North) - JCT Minor Works Building Contract (MW)1 award
Aptus Construction LtdSME, EFT Construction LtdSME, Seddon Construction Limited a 2 3 h 2 3, Senate Mech LtdSME, Walter Carefoot & Sons Ltd, Whitfield & Brown (Developments) LimitedSMEjoint awardLot: (1) Lot 1 (a) - England (North) - JCT Minor Works Building Contract (MW)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 2 · (b) - England (North) - JCT Intermediate Building Contract (IC)1 award
Aptus Construction LtdSME, Esh Construction Ltd. (2, 3), Frank Rogers Building Contractor LtdSME, Seddon Construction Limited a 2 3 h 2 3, Walter Carefoot & Sons Ltd, Whitfield & Brown (Developments) LimitedSMEjoint awardLot: (2) Lot 1 (b) - England (North) - JCT Intermediate Building Contract (IC)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 10 · (a) – England Midlands - JCT Minor Works Building Contract (MW)1 award
7 Formation Limited, Building Services NOW LtdSME, CBES Ltd, GALLAWAY CONSTRUCTION LIMITED, Seddon Construction Limited a 2 3 h 2 3, VINCI Construction UKjoint awardLot: (10) Lot 2 (a) – England Midlands - JCT Minor Works Building Contract (MW)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 11 · (b) - England Midlands- JCT Intermediate Building Contract (IC)1 award
Building Services NOW LtdSME, CBES Ltd, Etec Group, M & J GROUP (CONSTRUCTION & ROOFING) LTD, MBC Building Contractors, Seddon Construction Limited a 2 3 h 2 3joint awardLot: (11) Lot 2 (b) - England Midlands- JCT Intermediate Building Contract (IC)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 12 · (c) - England Midlands- JCT Design and Build Contract (D&B)1 award
Building Services NOW LtdSME, Galliford Try Construction Limited, John Graham Construction Ltd a 8 b 1 8 c 1 3 4 5 7 8 h 1 8, M & O BUILDING CONTRACTORS LIMITED, MYC Group (UK) Ltd, Seddon Construction Limited a 2 3 h 2 3joint awardLot: (12) Lot 2 (c) - England Midlands- JCT Design and Build Contract (D&B)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 13 · (d) – England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)1 award
Building Services NOW LtdSME, GALLAWAY CONSTRUCTION LIMITED, Galliford Try Construction Limited, John Graham Construction Ltd a 8 b 1 8 c 1 3 4 5 7 8 h 1 8, M & J GROUP (CONSTRUCTION & ROOFING) LTD, Seddon Construction Limited a 2 3 h 2 3joint awardLot: (13) Lot 2 (d) – England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 14 · (e) - England Midlands - NEC 4 Engineering and Construction Short Contract1 award
CBES Ltd, GALLAWAY CONSTRUCTION LIMITED, John Graham Construction Ltd a 8 b 1 8 c 1 3 4 5 7 8 h 1 8, M & J GROUP (CONSTRUCTION & ROOFING) LTD, MBC Building Contractors, Seddon Construction Limited a 2 3 h 2 3joint awardLot: (14) Lot 2 (e) - England Midlands - NEC 4 Engineering and Construction Short Contract1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 15 · (f) – England Midlands - NEC4 Engineering and Construction Contract1 award
Building Services NOW LtdSME, CBES Ltd, Galliford Try Construction Limited, John Graham Construction Ltd a 8 b 1 8 c 1 3 4 5 7 8 h 1 8, M & J GROUP (CONSTRUCTION & ROOFING) LTD, Seddon Construction Limited a 2 3 h 2 3joint awardLot: (15) Lot 2 (f) – England Midlands - NEC4 Engineering and Construction Contract1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 16 · (g) – England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract1 award
CBES Ltd, GMI Construction Group Plc, Galliford Try Construction Limited, John Graham Construction Ltd a 8 b 1 8 c 1 3 4 5 7 8 h 1 8, M & J GROUP (CONSTRUCTION & ROOFING) LTD, Seddon Construction Limited a 2 3 h 2 3joint awardLot: (16) Lot 2 (g) – England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 17 · (h) – England Midlands - NEC4 Engineering and Construction Contract with D&B1 award
Etec Group, GALLAWAY CONSTRUCTION LIMITED, GMI Construction Group Plc, Galliford Try Construction Limited, John Graham Construction Ltd a 8 b 1 8 c 1 3 4 5 7 8 h 1 8, M & J GROUP (CONSTRUCTION & ROOFING) LTD +1 morejoint awardLot: (17) Lot 2 (h) – England Midlands - NEC4 Engineering and Construction Contract with D&B1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 18 · (i) – England Midlands - National Federation of Demolition Contractors Direct Form of Contract1 award
DSM DemolitionSME, GLC Projects Ltd, MBC Building Contractors, Maylarch Environmental Ltd, Rhodar Ltdjoint awardLot: (18) Lot 2 (i) – England Midlands - National Federation of Demolition Contractors Direct Form of Contract1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1103 Jun 2026Awarded
Lot 19 · (a) – England South - JCT Minor Works Building Contract (MW)1 award
7 Formation Limited, Beard Construction, Beardwell Construction Limited, Carmelcrest Ltd, Every Project Counts LtdSME, Mulalley & Company Limitedjoint awardLot: (19) Lot 3 (a) – England South - JCT Minor Works Building Contract (MW)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 20 · (b) – England South - JCT Intermediate Building Contract (IC)1 award
Beard Construction, Beardwell Construction Limited, Carmelcrest Ltd, Etec Group, Knightsbridge Property services LtdSME, Mulalley & Company Limitedjoint awardLot: (20) Lot 3 (b) – England South - JCT Intermediate Building Contract (IC)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 21 · (c) - England South - JCT Design and Build Contract (D&B)1 award
Beard Construction, Beardwell Construction Limited, Galliford Try Construction Limited, John Graham Construction Ltd a 8 b 1 8 c 1 3 4 5 7 8 h 1 8, M & J GROUP (CONSTRUCTION & ROOFING) LTD, Mulalley & Company Limitedjoint awardLot: (21) Lot 3 (c) - England South - JCT Design and Build Contract (D&B)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded
Lot 22 · (d) – England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)1 award
Beard Construction, Beardwell Construction Limited, Galliford Try Construction Limited, John Graham Construction Ltd a 8 b 1 8 c 1 3 4 5 7 8 h 1 8, M & J GROUP (CONSTRUCTION & ROOFING) LTD, Mulalley & Company Limitedjoint awardLot: (22) Lot 3 (d) – England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months)£211,111,1113 Jun 2026Awarded

30 further award records carry no date or value.

Bid statistics published by the authority

LotBidsSMEVCSEValid bid range
1 · (a) - England (North) - JCT Minor Works Building Contract (MW)11final-stage tenders30—
2 · (b) - England (North) - JCT Intermediate Building Contract (IC)16final-stage tenders30—
3 · (c)– England (North) – JCT Design and Build Contract (D&B)10final-stage tenders00—
4 · (d) – England North – JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)11final-stage tenders20—
5 · (e) – England North – NEC 4 Engineering and Construction Short Contract12final-stage tenders30—
6 · (f) – England North – NEC4 Engineering and Construction Contract8final-stage tenders20—
7 · (g) – England North - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract10final-stage tenders20—
8 · (h) – England North - NEC4 Engineering and Construction Contract with D&B10final-stage tenders10—
9 · (i) – England North - National Federation of Demolition Contractors Direct Form of Contract6final-stage tenders00—
10 · (a) – England Midlands - JCT Minor Works Building Contract (MW)11final-stage tenders00—
11 · (b) - England Midlands- JCT Intermediate Building Contract (IC)11final-stage tenders10—
12 · (c) - England Midlands- JCT Design and Build Contract (D&B)8final-stage tenders00—
13 · (d) – England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)9final-stage tenders00—
14 · (e) - England Midlands - NEC 4 Engineering and Construction Short Contract8final-stage tenders10—
15 · (f) – England Midlands - NEC4 Engineering and Construction Contract10final-stage tenders10—
16 · (g) – England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract8final-stage tenders10—
17 · (h) – England Midlands - NEC4 Engineering and Construction Contract with D&B8final-stage tenders10—
18 · (i) – England Midlands - National Federation of Demolition Contractors Direct Form of Contract6final-stage tenders10—
19 · (a) – England South - JCT Minor Works Building Contract (MW)8final-stage tenders20—
20 · (b) – England South - JCT Intermediate Building Contract (IC)11final-stage tenders30—
21 · (c) - England South - JCT Design and Build Contract (D&B)12final-stage tenders10—
22 · (d) – England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)10final-stage tenders10—
23 · (e) - England South - NEC 4 Engineering and Construction Short Contract9final-stage tenders20—
24 · (f) – England South - NEC4 Engineering and Construction Contract9final-stage tenders20—
25 · (g) – England South - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract9final-stage tenders20—

Who bid

Bidders as named on the Procurement Act 2023 award notice. “Won” means the bidder holds an award on this notice.

Contracting authority & participating public bodies

Crescent Purchasing Consortium Limited

Contracting authorityPublic undertaking GB-PPON: PZPR-8554-XHNX Procurement House, Leslie Hough Way, Salford, North West, M6 6AJContact name, email, phone

Bidders & participating suppliers

50 commercial parties on the notice · 40 awarded
  • 7 FORMATION LIMITEDAwarded supplierGB-PPON: PZGV-6617-DMBY 23 Princewood Road, CORBY, East Midlands, NN17 4APContact name, email, phone
  • A.BUCKLER HAULAGE LIMITEDAwarded supplierGB-PPON: PHJX-3544-MTVP 24-28 Marsh Road, Middlesbrough, North East, TS1 5LBContact name, email, phone
  • A.R. CARTWRIGHT (CONSTRUCTION) LIMITEDBidder / tendererGB-PPON: PPQD-9154-VBML Vicarage Street, NUNEATON, West Midlands, CV11 4AZ
  • AREAAwarded supplierGB-PPON: PJZD-8216-PHJX Bridge House, 4 Borough High Street, Southwark, London, SE1 9QQContact name, email, phone
  • ASHFIELD PROJECTS (YORKSHIRE) LTDAwarded supplierGB-PPON: PBRQ-1568-JRLT Ashfield Projects (Yorkshire) Ltd, Sandown House, WETHERBY, Yorkshire & Humber, LS22 7DNContact name, email, phone
  • Aptus Construction LtdAwarded supplierGB-PPON: PTLR-9847-LWTH Unit 8 Cobblestone Court,, Hoults Yard, Newcastle-Upon-Tyne, North East, NE6 1ABContact name, email, phone
  • BSN Group Construction LtdAwarded supplierGB-PPON: PTHJ-9659-VXHZ Dudley Court South,, West ,, Waterfront East, Level Street, Brierley Hill, West Midlands, DY5 1TDContact name, email, phone
  • Beard ConstructionAwarded supplierGB-PPON: PJPB-5212-BNDP Faraday Road, Dorcan, Swindon, South West, SN3 5JYContact name, email, phone
  • Beardwell Construction LtdAwarded supplierGB-PPON: PBJZ-9979-PBMW Beacon House, Threshelfords Business Park,, Inworth Road, Colchester, East of England, CO5 9SEContact name, email, phone
  • Brims Construction LtdBidder / tendererGB-PPON: PHBV-8337-DNQL Ravensworth House, 5th Avenue Business Park, Gateshead, North East, NE11 0HF
Show 40 more suppliers
  • C.G. FRY AND SON LIMITEDBidder / tendererGB-PPON: PBTV-4868-CNJH Litton Cheney, , DORCHESTER, South West, DT2 9AS
  • CBESAwarded supplierGB-PPON: PYBB-4931-GPPD Caledonia House, Lawmoor Street, Glasgow, Scotland, G5 0USContact name, email, phone
  • CCG (SCOTLAND) LIMITEDAwarded supplierGB-PPON: PWGZ-4584-LXJJ 1 Cambuslang Road, Cambuslang Investment Park, GLASGOW, Scotland, G32 8NBContact name, email, phone
  • CITYAXIS LIMITEDAwarded supplierGB-PPON: PHTT-9248-ZXMG 1St Floor, 346 Kensington High Street, Kensington, 346 Kensington High Street, LONDON, London, W14 8NSContact name, email, phone
  • Carmelcrest LimitedAwarded supplierGB-PPON: PGXX-7212-MLBQ Suite 18, Block H, Peek Business Centre, Dunmow Road, Bishop's Stortford, East of England, CM23 5RGContact name, email, phone
  • Compass Developments (NE) LtdAwarded supplierGB-PPON: PBPY-4769-XNBL Unit 9 Trafalgar Court, South Nelson Industrial Estate, Cramlington, North East, NE23 1WFContact name, email, phone
  • D R W LTD.Awarded supplierGB-PPON: PBPD-9992-MNVW Unit 2 , 1 Annan Business Park, ANNAN, Scotland, DG12 6TZContact name, email, phone
  • DSM (DSM DEMOLITION LIMITED)Awarded supplierGB-PPON: PDNC-5796-MJWT Arden House Arden Road, BIRMINGHAM, West Midlands, B8 1DEContact name, email, phone
  • EFT Construction LtdAwarded supplierGB-PPON: PRLW-6359-JLDP Cobden House, 39A Cobden Road, Southport, North West, PR9 7TRContact name, email, phone
  • Esh Construction LimitedAwarded supplierGB-PPON: PRJV-5614-DHMZ Esh House, Bowburn North Ind Est, Durham, North East, DH6 5PFContact name, email, phone
  • Etec GroupAwarded supplierGB-PPON: PTRJ-1317-LMRY 98 High Road, 98/106 High Road, South Woodford, London, E182QHContact name, email, phone
  • Every Project Counts LtdAwarded supplierGB-PPON: PCMN-5796-PHGT Unit 7, Kendal Court, Wickford, East of England, SS11 8YBContact name, email, phone
  • FRANK ROGERS (BUILDING CONTRACTOR) LIMITEDAwarded supplierGB-PPON: PZRH-8617-DHJT The Stables, Larkhill Lane, LIVERPOOL, North West, L13 9BRContact name, email, phone
  • GALLAWAY CONSTRUCTION LIMITEDAwarded supplierGB-PPON: PJVM-7393-WBVP The Old School House, Manchester Road, Manchester, North West, M31 4UGContact name, email, phone
  • GLC PROJECTS LTDAwarded supplierGB-PPON: PTBP-9736-DCWD The Manor House, West End, Sedgefield, North East, TS21 2BWContact name, email, phone
  • GMI CONSTRUCTION GROUP PLCAwarded supplierGB-PPON: PDLR-6293-DLGH Middleton House, Westland Road, LEEDS, Yorkshire & Humber, LS11 5UHContact name, email, phone
  • GRAHAMAwarded supplierGB-PPON: PGTW-4456-TGCY 5 BALLYGOWAN ROAD, Hillsborough, Northern Ireland, BT26 6HXContact name, email, phone
  • Galliford Try Construction LimitedAwarded supplierGB-PPON: PYQH-7266-GDPX Blake House 3 , Frayswater Place, Uxbridge, London, UB8 2ADContact name, email, phone
  • John Turner Construction Group LtdBidder / tendererGB-PPON: PWNL-8777-NNQX 2 Preston Road, Grimsargh, Preston, North West, PR2 5SD
  • Jupiter Construction LTDBidder / tendererGB-PPON: PHWR-8769-WWGL Unit 6a, Mortec Park, Leeds, Yorkshire & Humber, LS15 4TA
  • Knightsbridge Property Services LtdAwarded supplierGB-PPON: PTZX-3371-DHCD Airport House, Purley Way, Croydon, London, CR0 0XZContact name, email, phone
  • M & J Group (Construction & Roofing) Ltd.Awarded supplierGB-PPON: PMMH-8591-VGTY Hammond Road, Elms Ind Estate, Bedford, East of England, MK41 0UDContact name, email, phone
  • M & O BUILDING CONTRACTORS LIMITEDAwarded supplierGB-PPON: PJNB-7236-ZVCQ York House, Leicester Road , LEICESTER, East Midlands, LE17 4HFContact name, email, phone
  • MBC Building ContractorsAwarded supplierGB-PPON: PLDN-9791-PJGH Lyceum Works, George Street, Chadderton, North West, OL9 9HYContact name, email, phone
  • MYC Group LtdAwarded supplierGB-PPON: PQZD-6932-BDNH 28 St. Albans Lane, LONDON, London, NW11 7QEContact name, email, phone
  • Maylarch Environmental LtdAwarded supplierGB-PPON: PTXD-1133-HVRW Stable Courtyard, Worton Park, Witney, South East, OX29 4SUContact name, email, phone
  • Mulalley and Company LtdAwarded supplierGB-PPON: PDVH-1753-WZJH Teresa Gavin House , Woodford Avenue, Woodford, London, IG8 8FAContact name, email, phone
  • NRC Services LimitedBidder / tendererGB-PPON: PZQD-1942-MTWY N R C House, Titterton Street, Sheffield, Yorkshire & Humber, S9 3TE
  • PLANET INTERIOR PROJECTS LIMITEDAwarded supplierGB-PPON: PDJQ-6122-BMVY Empress Business Park, 380 Chester Road, MANCHESTER, North West, M16 9EAContact name, email, phone
  • Premier Modular LtdAwarded supplierGB-PPON: PBPZ-4782-JBVH Catfoss Lane, Brandesburton, Yorkshire & Humber, YO25 8EJContact name, email, phone
  • RHODAR INDUSTRIAL SERVICES LIMITEDAwarded supplierGB-PPON: PXDY-7891-BHYG Unit C, Astra Park, Parkside Lane, LEEDS, Yorkshire & Humber, LS11 5SZContact name, email, phone
  • Rosslee Construction LtdBidder / tendererGB-PPON: PYRJ-3189-GLDM 30 Black Abbey Street, Accrington, North West, BB5 1HT
  • Seddon Construction LimitedAwarded supplierGB-PPON: PRRH-8298-MPBM Plodder Lane, Edge Fold, Bolton, North West, BL4 0NNContact name, email, phone
  • Senate Mech LtdAwarded supplierGB-PPON: PVXV-4192-PRXH Senate Mech Ltd, , 13 Love Lane , Liverpool, North West, L3 7DDContact name, email, phone
  • Standage & Co. LimitedBidder / tendererGB-PPON: PLBB-6351-LDWL Unit 8, Glengall Business Centre, London, London, SE15 6NH
  • TOTAL PROTECTION (CONTRACTING SERVICES) LTDBidder / tendererGB-PPON: PPTX-1438-QCTR Monometer House, Rectory Grove, LEIGH-ON-SEA, East of England, SS9 2HN
  • VINCI FacilitiesAwarded supplierGB-PPON: PBXL-9667-CZWP Stuart House, Manor Way, Rainham, London, RM13 8RHContact name, email, phone
  • Walter Carefoot & Sons (Construction) Ltd.Awarded supplierGB-PPON: PTBH-4688-MMXN Blackpool Road, Longridge, Preston, North West, PR3 3ALContact name, email, phone
  • Whitfield & Brown (Developments) LtdAwarded supplierGB-PPON: PWDD-8548-WNWN Halton House, Gorsey Lane, Widnes, North West, WA8 0RPContact name, email, phone
  • Willliam Birch & Sons LtdBidder / tendererGB-PPON: PRGP-6331-RLDT Link Road Court, Osbaldwick, York, Yorkshire & Humber, YO10 3JQ

Official documents & specifications (138)

Official links; attachments are not copied

Notices published for this procedure

  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
Show 22 more notices
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender
  • Contract award notice awardContract award noticeUK6Contract award notice on Find a Tender

108 further documents are listed in the JSON mirror.