Unmodified official OCDS data retained by Tenderline for this procurement process.
Complete current OCDS release JSON
{
"id": "039543-2024",
"tag": [
"award",
"contract"
],
"bids": {
"statistics": [
{
"id": "1",
"value": 7,
"measure": "bids",
"relatedLot": "1"
},
{
"id": "2",
"value": 7,
"measure": "electronicBids",
"relatedLot": "1"
}
]
},
"date": "2024-12-09T10:12:44Z",
"ocid": "ocds-h6vhtk-04931f",
"buyer": {
"id": "GB-FTS-80139",
"name": "Cumberland Council"
},
"awards": [
{
"id": "039543-2024-1",
"title": "Workington Gateway - Stage 1 only",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-115047",
"name": "Story Contracting Ltd"
}
],
"relatedLots": [
"1"
]
}
],
"tender": {
"id": "DN739098",
"lots": [
{
"id": "1",
"status": "cancelled",
"hasOptions": false,
"description": "Cumberland Council has embarked on a £10.6 million project to open up a key area of Workington and improve HGV access. The location involves the A66 and A596 at Ramsay Brow and Hall Brow, two of the main roads into the town, which form an important route to the Port of Workington and other major business areas to the north of the town.\nThere are currently a number of projects underway within Workington Town Centre, all from different funding sources, with different timescales. The Contractor should familiarise themselves with the programme of works and liaise with the Project Manager and other Contractors when planning works to avoid disrupting the works, minimise delays on the road network and maintain access to premises.\nhttps://www.cumberland.gov.uk/planning-and-building-control/regeneration-project/workington-projects\nThe estimated total value of stage 1 contract is £190,000.00\nexcluding VAT.\nThe estimated total value of stage 2 contract is £3,600,000.00\nexcluding VAT.\nDetails of current expenditure are indicative only and the Council does not guarantee any spend against this Contract.\nThe Council will commission the Works in two distinct stages:\n• Stage 1: Design, development, consents and approvals.\n• Stage 2: Construction\nThere will be an Employer decision hold-point between Stage 1 and 2 when the Employer will decide whether or not to proceed to Stage 2. This decision will be at the Employers total discretion.\nStage 1 will be administered under an NEC3 Engineering Construction Contract (Option A).\nStage 2 will be administered under a separate NEC3 Engineering Construction Contract (Option A).\nFor Stage 1, the Contractor will enter into a Contract with the Council (the Employer) and develop the detailed design and produce the works information for the works as described in the Works Information. It should be noted that whilst an RIBA Stage 3 (preliminary) design has been developed (drawings included as previously referenced), the Council will appoint a Contractor to accept the preliminary design and progress it through detailed design and production of works information involving the Contractors experience for risk management and ‘buildability’ which shall be incorporated into the works information.\nThe Contractor will undertake any necessary supplementary investigations, studies, assessments, etc., produce all drawings, schedules and specifications for the works; identify and secure all necessary consents and approvals to enable successful construction of the works. The Contractor will provide pre-construction information (PCI) and site information as well as a Stage 2 priced activity schedule, quantified risk register and Cl31 programme for acceptance at the end of\nStage 1.\nIf the Employer accepts the Stage 1 products and the Contractors Stage 2 price, the Contractor will be appointed to provide the Stage 2 works.\nFor the avoidance of doubt, the initial contract will be for the provision of Stage 1 works only. The Employer has no contractual obligation to commit to Stage 2 works. Additional information: Suppliers wishing to express an interest and obtain access to the tender documents should go to www.the-chest.org.uk and click on current opportunities from the navigation area on the left of the screen. On the next screen enter the contract Reference DN739098 in the box labelled 'contains' then click search. Click on the Blue link for the contract title to view the opportunity.\nTo express an interest you will need to login. If you are not already registered on the www.the-chest.org.uk you will need to return to the home page and click on Register. Register free link in the navigation area on the left of the screen. Registration is free of charge and your username and password will be emailed to you.\nCumberland Council is fully supportive of all aspects of diversity including ethnicity, race, religion, age, disability and sexual orientation. In this respect Cumberland Council welcomes expressions of interest from ethnic minority, disabled and other diverse business communities and the voluntary sector. Economic operators are therefore required to fully comply with all statutory obligations/applicable legislation and there will be a requirement to participate in the authority's supplier audits on all aspects of diversity.\nThe contracting authority expressly reserves the right:\n(i) not to award any contract as a result of the procurement process commenced by publication of this notice; and\n(ii) to make whatever changes it may see fit to the content and structure of the tendering competition; and in no circumstances will the contracting authority be liable for any costs incurred by the candidates. Any expenditure, work or effort undertaken prior to contract award is accordingly a matter solely for the commercial judgement of potential suppliers.\nThe contracting authority reserve the right to use any electronic portal during the life of the agreement.\nThe value provided in Section II.1.5 is only an estimate.",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "60"
},
{
"name": "Social Value",
"type": "quality",
"description": "10"
},
{
"type": "price",
"description": "30"
}
]
}
}
],
"items": [
{
"id": "1",
"relatedLot": "1",
"deliveryAddresses": [
{
"region": "UKD1"
}
]
}
],
"title": "Workington Gateway",
"status": "complete",
"coveredBy": [
"GPA"
],
"legalBasis": {
"id": "32014L0024",
"scheme": "CELEX"
},
"description": "The Project forms part of the wider Workington Gateway programme, which is made up of the following elements:\n1. Ramsay Brow junction (A66/A596) improvement to improve access to strategic employment sites, including the Port of Workington.\n2. Road widening of Hall Brow (A596) to improve access to strategic employment sites, including the Port of Workington.\n3. Local active travel network improvements and enhanced public realm, including a new LTN1/20 compliant east-west cycle route through Hall Park running parallel and complementary to the A66, supporting proposals in the Local Cycling and Walking Infrastructure Plan (LCWIP).\n4. Enhancement of the cultural offer and visitor experience within Hall Park, including creation of a Social Enterprise Centre within the Walled Garden, and feature lighting of Workington Hall.\nThis Project will generally comprise:\n• Realignment and widening of the A66 Ramsay Brow/ A596 junction, allowing HGV movement from the A66 to the employment and distribution sites north of Workington.\no A pocket park to replace the existing Henry’s pub site with improved public realm, seating and a landscaped area.\no New toucan crossings on the eastern and southern arms of the junction.\no New cycle infrastructure along the A596 eastern footway between the A66 and Ladies Walk.\no Widening of the A66 Ramsay Brow southern footway to achieve minimum 2m width throughout.\n• Widening of the A596 Hall Brow, allowing HGV movement from the A66 to the employment and distribution sites north of Workington.\no Formal permit-holder only parking for the Hall Brow residents.\no Relocated existing park boundary wall to accommodate carriageway widening.\no New parallel Toucan crossing for pedestrians and cyclists across the A596, connecting Black Path to the park.\nThe Project will be delivered in two stages:\nStage 1: Design and production of Stage 2 Works Information: Administered under NEC3 ECC Option A.\nStage 2: Construction: Administered under a separate NEC3 ECC Option A.\nThere will be a decision hold-point between Stage 1 and Stage 2 where the Employer may choose to proceed, or not to proceed to Stage 2.",
"classification": {
"id": "45000000",
"scheme": "CPV",
"description": "Construction work"
},
"procurementMethod": "open",
"mainProcurementCategory": "works",
"procurementMethodDetails": "Open procedure"
},
"parties": [
{
"id": "GB-FTS-80139",
"name": "Cumberland Council",
"roles": [
"buyer"
],
"address": {
"region": "UKD1",
"locality": "Carlisle",
"postalCode": "CA1 1RD",
"countryName": "United Kingdom",
"streetAddress": "Cumbria House, 107 - 117 Botchergate"
},
"details": {
"url": "https://www.cumberland.gov.uk/",
"buyerProfile": "https://www.cumberland.gov.uk/",
"classifications": [
{
"id": "REGIONAL_AUTHORITY",
"scheme": "TED_CA_TYPE",
"description": "Regional or local authority"
},
{
"id": "01",
"scheme": "COFOG",
"description": "General public services"
}
]
},
"identifier": {
"legalName": "Cumberland Council"
},
"contactPoint": {
"email": "procurement.capital@cumberland.gov.uk"
}
},
{
"id": "GB-FTS-115047",
"name": "Story Contracting Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKD1",
"locality": "Carlisle",
"countryName": "United Kingdom"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "Story Contracting Ltd"
}
},
{
"id": "GB-FTS-122338",
"name": "The High Court Of England",
"roles": [
"reviewBody"
],
"address": {
"locality": "London",
"countryName": "United Kingdom"
},
"identifier": {
"legalName": "The High Court Of England"
}
}
],
"language": "en",
"contracts": [
{
"id": "039543-2024-1",
"title": "Workington Gateway - Stage 1 only",
"value": {
"amount": 224334.97,
"currency": "GBP"
},
"status": "active",
"awardID": "039543-2024-1",
"dateSigned": "2024-11-22T00:00:00Z"
}
],
"initiationType": "tender"
}Complete JSON history (3 releases)
9 Dec 2024 · 039543-2024 · award, contract
{
"id": "039543-2024",
"tag": [
"award",
"contract"
],
"bids": {
"statistics": [
{
"id": "1",
"value": 7,
"measure": "bids",
"relatedLot": "1"
},
{
"id": "2",
"value": 7,
"measure": "electronicBids",
"relatedLot": "1"
}
]
},
"date": "2024-12-09T10:12:44Z",
"ocid": "ocds-h6vhtk-04931f",
"buyer": {
"id": "GB-FTS-80139",
"name": "Cumberland Council"
},
"awards": [
{
"id": "039543-2024-1",
"title": "Workington Gateway - Stage 1 only",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-115047",
"name": "Story Contracting Ltd"
}
],
"relatedLots": [
"1"
]
}
],
"tender": {
"id": "DN739098",
"lots": [
{
"id": "1",
"status": "cancelled",
"hasOptions": false,
"description": "Cumberland Council has embarked on a £10.6 million project to open up a key area of Workington and improve HGV access. The location involves the A66 and A596 at Ramsay Brow and Hall Brow, two of the main roads into the town, which form an important route to the Port of Workington and other major business areas to the north of the town.\nThere are currently a number of projects underway within Workington Town Centre, all from different funding sources, with different timescales. The Contractor should familiarise themselves with the programme of works and liaise with the Project Manager and other Contractors when planning works to avoid disrupting the works, minimise delays on the road network and maintain access to premises.\nhttps://www.cumberland.gov.uk/planning-and-building-control/regeneration-project/workington-projects\nThe estimated total value of stage 1 contract is £190,000.00\nexcluding VAT.\nThe estimated total value of stage 2 contract is £3,600,000.00\nexcluding VAT.\nDetails of current expenditure are indicative only and the Council does not guarantee any spend against this Contract.\nThe Council will commission the Works in two distinct stages:\n• Stage 1: Design, development, consents and approvals.\n• Stage 2: Construction\nThere will be an Employer decision hold-point between Stage 1 and 2 when the Employer will decide whether or not to proceed to Stage 2. This decision will be at the Employers total discretion.\nStage 1 will be administered under an NEC3 Engineering Construction Contract (Option A).\nStage 2 will be administered under a separate NEC3 Engineering Construction Contract (Option A).\nFor Stage 1, the Contractor will enter into a Contract with the Council (the Employer) and develop the detailed design and produce the works information for the works as described in the Works Information. It should be noted that whilst an RIBA Stage 3 (preliminary) design has been developed (drawings included as previously referenced), the Council will appoint a Contractor to accept the preliminary design and progress it through detailed design and production of works information involving the Contractors experience for risk management and ‘buildability’ which shall be incorporated into the works information.\nThe Contractor will undertake any necessary supplementary investigations, studies, assessments, etc., produce all drawings, schedules and specifications for the works; identify and secure all necessary consents and approvals to enable successful construction of the works. The Contractor will provide pre-construction information (PCI) and site information as well as a Stage 2 priced activity schedule, quantified risk register and Cl31 programme for acceptance at the end of\nStage 1.\nIf the Employer accepts the Stage 1 products and the Contractors Stage 2 price, the Contractor will be appointed to provide the Stage 2 works.\nFor the avoidance of doubt, the initial contract will be for the provision of Stage 1 works only. The Employer has no contractual obligation to commit to Stage 2 works. Additional information: Suppliers wishing to express an interest and obtain access to the tender documents should go to www.the-chest.org.uk and click on current opportunities from the navigation area on the left of the screen. On the next screen enter the contract Reference DN739098 in the box labelled 'contains' then click search. Click on the Blue link for the contract title to view the opportunity.\nTo express an interest you will need to login. If you are not already registered on the www.the-chest.org.uk you will need to return to the home page and click on Register. Register free link in the navigation area on the left of the screen. Registration is free of charge and your username and password will be emailed to you.\nCumberland Council is fully supportive of all aspects of diversity including ethnicity, race, religion, age, disability and sexual orientation. In this respect Cumberland Council welcomes expressions of interest from ethnic minority, disabled and other diverse business communities and the voluntary sector. Economic operators are therefore required to fully comply with all statutory obligations/applicable legislation and there will be a requirement to participate in the authority's supplier audits on all aspects of diversity.\nThe contracting authority expressly reserves the right:\n(i) not to award any contract as a result of the procurement process commenced by publication of this notice; and\n(ii) to make whatever changes it may see fit to the content and structure of the tendering competition; and in no circumstances will the contracting authority be liable for any costs incurred by the candidates. Any expenditure, work or effort undertaken prior to contract award is accordingly a matter solely for the commercial judgement of potential suppliers.\nThe contracting authority reserve the right to use any electronic portal during the life of the agreement.\nThe value provided in Section II.1.5 is only an estimate.",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "60"
},
{
"name": "Social Value",
"type": "quality",
"description": "10"
},
{
"type": "price",
"description": "30"
}
]
}
}
],
"items": [
{
"id": "1",
"relatedLot": "1",
"deliveryAddresses": [
{
"region": "UKD1"
}
]
}
],
"title": "Workington Gateway",
"status": "complete",
"coveredBy": [
"GPA"
],
"legalBasis": {
"id": "32014L0024",
"scheme": "CELEX"
},
"description": "The Project forms part of the wider Workington Gateway programme, which is made up of the following elements:\n1. Ramsay Brow junction (A66/A596) improvement to improve access to strategic employment sites, including the Port of Workington.\n2. Road widening of Hall Brow (A596) to improve access to strategic employment sites, including the Port of Workington.\n3. Local active travel network improvements and enhanced public realm, including a new LTN1/20 compliant east-west cycle route through Hall Park running parallel and complementary to the A66, supporting proposals in the Local Cycling and Walking Infrastructure Plan (LCWIP).\n4. Enhancement of the cultural offer and visitor experience within Hall Park, including creation of a Social Enterprise Centre within the Walled Garden, and feature lighting of Workington Hall.\nThis Project will generally comprise:\n• Realignment and widening of the A66 Ramsay Brow/ A596 junction, allowing HGV movement from the A66 to the employment and distribution sites north of Workington.\no A pocket park to replace the existing Henry’s pub site with improved public realm, seating and a landscaped area.\no New toucan crossings on the eastern and southern arms of the junction.\no New cycle infrastructure along the A596 eastern footway between the A66 and Ladies Walk.\no Widening of the A66 Ramsay Brow southern footway to achieve minimum 2m width throughout.\n• Widening of the A596 Hall Brow, allowing HGV movement from the A66 to the employment and distribution sites north of Workington.\no Formal permit-holder only parking for the Hall Brow residents.\no Relocated existing park boundary wall to accommodate carriageway widening.\no New parallel Toucan crossing for pedestrians and cyclists across the A596, connecting Black Path to the park.\nThe Project will be delivered in two stages:\nStage 1: Design and production of Stage 2 Works Information: Administered under NEC3 ECC Option A.\nStage 2: Construction: Administered under a separate NEC3 ECC Option A.\nThere will be a decision hold-point between Stage 1 and Stage 2 where the Employer may choose to proceed, or not to proceed to Stage 2.",
"classification": {
"id": "45000000",
"scheme": "CPV",
"description": "Construction work"
},
"procurementMethod": "open",
"mainProcurementCategory": "works",
"procurementMethodDetails": "Open procedure"
},
"parties": [
{
"id": "GB-FTS-80139",
"name": "Cumberland Council",
"roles": [
"buyer"
],
"address": {
"region": "UKD1",
"locality": "Carlisle",
"postalCode": "CA1 1RD",
"countryName": "United Kingdom",
"streetAddress": "Cumbria House, 107 - 117 Botchergate"
},
"details": {
"url": "https://www.cumberland.gov.uk/",
"buyerProfile": "https://www.cumberland.gov.uk/",
"classifications": [
{
"id": "REGIONAL_AUTHORITY",
"scheme": "TED_CA_TYPE",
"description": "Regional or local authority"
},
{
"id": "01",
"scheme": "COFOG",
"description": "General public services"
}
]
},
"identifier": {
"legalName": "Cumberland Council"
},
"contactPoint": {
"email": "procurement.capital@cumberland.gov.uk"
}
},
{
"id": "GB-FTS-115047",
"name": "Story Contracting Ltd",
"roles": [
"supplier"
],
"address": {
"region": "UKD1",
"locality": "Carlisle",
"countryName": "United Kingdom"
},
"details": {
"scale": "large"
},
"identifier": {
"legalName": "Story Contracting Ltd"
}
},
{
"id": "GB-FTS-122338",
"name": "The High Court Of England",
"roles": [
"reviewBody"
],
"address": {
"locality": "London",
"countryName": "United Kingdom"
},
"identifier": {
"legalName": "The High Court Of England"
}
}
],
"language": "en",
"contracts": [
{
"id": "039543-2024-1",
"title": "Workington Gateway - Stage 1 only",
"value": {
"amount": 224334.97,
"currency": "GBP"
},
"status": "active",
"awardID": "039543-2024-1",
"dateSigned": "2024-11-22T00:00:00Z"
}
],
"initiationType": "tender"
}29 Aug 2024 · 027538-2024 · tenderUpdate
{
"id": "027538-2024",
"tag": [
"tenderUpdate"
],
"date": "2024-08-29T11:52:23+01:00",
"ocid": "ocds-h6vhtk-04931f",
"buyer": {
"id": "GB-FTS-80139",
"name": "Cumberland Council"
},
"tender": {
"id": "DN739098",
"title": "Workington Gateway",
"amendments": [
{
"id": "1",
"unstructuredChanges": [
{
"where": {
"label": "Time limit for receipt of tenders or requests to participate",
"section": "IV.2.2"
},
"newValue": {
"date": "2024-10-11T12:00:00+01:00"
},
"oldValue": {
"date": "2024-09-27T12:00:00+01:00"
}
},
{
"where": {
"label": "Conditions for opening of tenders",
"section": "IV.2.7"
},
"newValue": {
"date": "2024-10-11T12:00:00+01:00"
},
"oldValue": {
"date": "2024-09-27T12:00:00+01:00"
}
}
]
}
],
"legalBasis": {
"id": "32014L0024",
"scheme": "CELEX"
},
"description": "The Project forms part of the wider Workington Gateway programme, which is made up of the following elements:\n1. Ramsay Brow junction (A66/A596) improvement to improve access to strategic employment sites, including the Port of Workington.\n2. Road widening of Hall Brow (A596) to improve access to strategic employment sites, including the Port of Workington.\n3. Local active travel network improvements and enhanced public realm, including a new LTN1/20 compliant east-west cycle route through Hall Park running parallel and complementary to the A66, supporting proposals in the Local Cycling and Walking Infrastructure Plan (LCWIP).\n4. Enhancement of the cultural offer and visitor experience within Hall Park, including creation of a Social Enterprise Centre within the Walled Garden, and feature lighting of Workington Hall.\nThis Project will generally comprise:\n• Realignment and widening of the A66 Ramsay Brow/ A596 junction, allowing HGV movement from the A66 to the employment and distribution sites north of Workington.\no A pocket park to replace the existing Henry’s pub site with improved public realm, seating and a landscaped area.\no New toucan crossings on the eastern and southern arms of the junction.\no New cycle infrastructure along the A596 eastern footway between the A66 and Ladies Walk.\no Widening of the A66 Ramsay Brow southern footway to achieve minimum 2m width throughout.\n• Widening of the A596 Hall Brow, allowing HGV movement from the A66 to the employment and distribution sites north of Workington.\no Formal permit-holder only parking for the Hall Brow residents.\no Relocated existing park boundary wall to accommodate carriageway widening.\no New parallel Toucan crossing for pedestrians and cyclists across the A596, connecting Black Path to the park.\nThe Project will be delivered in two stages:\nStage 1: Design and production of Stage 2 Works Information: Administered under NEC3 ECC Option A.\nStage 2: Construction: Administered under a separate NEC3 ECC Option A.\nThere will be a decision hold-point between Stage 1 and Stage 2 where the Employer may choose to proceed, or not to proceed to Stage 2.",
"classification": {
"id": "45000000",
"scheme": "CPV",
"description": "Construction work"
},
"mainProcurementCategory": "works"
},
"parties": [
{
"id": "GB-FTS-80139",
"name": "Cumberland Council",
"roles": [
"buyer"
],
"address": {
"region": "UKD1",
"locality": "Carlisle",
"postalCode": "CA1 1RD",
"countryName": "United Kingdom",
"streetAddress": "Cumbria House, 107 - 117 Botchergate"
},
"details": {
"url": "https://www.cumberland.gov.uk/",
"buyerProfile": "https://www.cumberland.gov.uk/"
},
"identifier": {
"legalName": "Cumberland Council"
},
"contactPoint": {
"email": "procurement.capital@cumberland.gov.uk"
}
}
],
"language": "en",
"initiationType": "tender"
}22 Aug 2024 · 026896-2024 · tender
{
"id": "026896-2024",
"tag": [
"tender"
],
"date": "2024-08-22T15:55:57+01:00",
"ocid": "ocds-h6vhtk-04931f",
"buyer": {
"id": "GB-FTS-80139",
"name": "Cumberland Council"
},
"tender": {
"id": "DN739098",
"lots": [
{
"id": "1",
"status": "active",
"hasOptions": false,
"hasRenewal": false,
"description": "Cumberland Council has embarked on a £10.6 million project to open up a key area of Workington and improve HGV access. The location involves the A66 and A596 at Ramsay Brow and Hall Brow, two of the main roads into the town, which form an important route to the Port of Workington and other major business areas to the north of the town.\nThere are currently a number of projects underway within Workington Town Centre, all from different funding sources, with different timescales. The Contractor should familiarise themselves with the programme of works and liaise with the Project Manager and other Contractors when planning works to avoid disrupting the works, minimise delays on the road network and maintain access to premises.\nhttps://www.cumberland.gov.uk/planning-and-building-control/regeneration-project/workington-projects\nThe estimated total value of stage 1 contract is £190,000.00\nexcluding VAT.\nThe estimated total value of stage 2 contract is £3,600,000.00\nexcluding VAT.\nDetails of current expenditure are indicative only and the Council does not guarantee any spend against this Contract.\nThe Council will commission the Works in two distinct stages:\n•\tStage 1: Design, development, consents and approvals.\n•\tStage 2: Construction\nThere will be an Employer decision hold-point between Stage 1 and 2 when the Employer will decide whether or not to proceed to Stage 2. This decision will be at the Employers total discretion.\nStage 1 will be administered under an NEC3 Engineering Construction Contract (Option A).\nStage 2 will be administered under a separate NEC3 Engineering Construction Contract (Option A).\nFor Stage 1, the Contractor will enter into a Contract with the Council (the Employer) and develop the detailed design and produce the works information for the works as described in the Works Information. It should be noted that whilst an RIBA Stage 3 (preliminary) design has been developed (drawings included as previously referenced), the Council will appoint a Contractor to accept the preliminary design and progress it through detailed design and production of works information involving the Contractors experience for risk management and ‘buildability’ which shall be incorporated into the works information.\nThe Contractor will undertake any necessary supplementary investigations, studies, assessments, etc., produce all drawings, schedules and specifications for the works; identify and secure all necessary consents and approvals to enable successful construction of the works. The Contractor will provide pre-construction information (PCI) and site information as well as a Stage 2 priced activity schedule, quantified risk register and Cl31 programme for acceptance at the end of\nStage 1.\nIf the Employer accepts the Stage 1 products and the Contractors Stage 2 price, the Contractor will be appointed to provide the Stage 2 works.\nFor the avoidance of doubt, the initial contract will be for the provision of Stage 1 works only. The Employer has no contractual obligation to commit to Stage 2 works. Additional information: Suppliers wishing to express an interest and obtain access to the tender documents should go to www.the-chest.org.uk and click on current opportunities from the navigation area on the left of the screen. On the next screen enter the contract Reference DN739098 in the box labelled 'contains' then click search. Click on the Blue link for the contract title to view the opportunity.\nTo express an interest you will need to login. If you are not already registered on the www.the-chest.org.uk you will need to return to the home page and click on Register. Register free link in the navigation area on the left of the screen. Registration is free of charge and your username and password will be emailed to you.\nCumberland Council is fully supportive of all aspects of diversity including ethnicity, race, religion, age, disability and sexual orientation. In this respect Cumberland Council welcomes expressions of interest from ethnic minority, disabled and other diverse business communities and the voluntary sector. Economic operators are therefore required to fully comply with all statutory obligations/applicable legislation and there will be a requirement to participate in the authority's supplier audits on all aspects of diversity.\nThe contracting authority expressly reserves the right:\n(i) not to award any contract as a result of the procurement process commenced by publication of this notice; and\n(ii) to make whatever changes it may see fit to the content and structure of the tendering competition; and in no circumstances will the contracting authority be liable for any costs incurred by the candidates. Any expenditure, work or effort undertaken prior to contract award is accordingly a matter solely for the commercial judgement of potential suppliers.\nThe contracting authority reserve the right to use any electronic portal during the life of the agreement.\nThe value provided in Section II.1.5 is only an estimate.",
"awardCriteria": {
"criteria": [
{
"name": "Quality",
"type": "quality",
"description": "60"
},
{
"name": "Social Value",
"type": "quality",
"description": "10"
},
{
"type": "price",
"description": "30"
}
]
},
"contractPeriod": {
"durationInDays": 420
},
"submissionTerms": {
"variantPolicy": "notAllowed"
}
}
],
"items": [
{
"id": "1",
"relatedLot": "1",
"deliveryAddresses": [
{
"region": "UKD1"
}
]
}
],
"title": "Workington Gateway",
"value": {
"amount": 3790000,
"currency": "GBP"
},
"status": "active",
"coveredBy": [
"GPA"
],
"documents": [
{
"id": "economic",
"documentType": "economicSelectionCriteria"
},
{
"id": "technical",
"documentType": "technicalSelectionCriteria"
}
],
"bidOpening": {
"date": "2024-09-27T12:00:00+01:00"
},
"legalBasis": {
"id": "32014L0024",
"scheme": "CELEX"
},
"awardPeriod": {
"startDate": "2024-09-27T12:00:00+01:00"
},
"description": "The Project forms part of the wider Workington Gateway programme, which is made up of the following elements:\n1. Ramsay Brow junction (A66/A596) improvement to improve access to strategic employment sites, including the Port of Workington.\n2. Road widening of Hall Brow (A596) to improve access to strategic employment sites, including the Port of Workington.\n3. Local active travel network improvements and enhanced public realm, including a new LTN1/20 compliant east-west cycle route through Hall Park running parallel and complementary to the A66, supporting proposals in the Local Cycling and Walking Infrastructure Plan (LCWIP).\n4. Enhancement of the cultural offer and visitor experience within Hall Park, including creation of a Social Enterprise Centre within the Walled Garden, and feature lighting of Workington Hall.\nThis Project will generally comprise:\n• Realignment and widening of the A66 Ramsay Brow/ A596 junction, allowing HGV movement from the A66 to the employment and distribution sites north of Workington.\no A pocket park to replace the existing Henry’s pub site with improved public realm, seating and a landscaped area.\no New toucan crossings on the eastern and southern arms of the junction.\no New cycle infrastructure along the A596 eastern footway between the A66 and Ladies Walk.\no Widening of the A66 Ramsay Brow southern footway to achieve minimum 2m width throughout.\n• Widening of the A596 Hall Brow, allowing HGV movement from the A66 to the employment and distribution sites north of Workington.\no Formal permit-holder only parking for the Hall Brow residents.\no Relocated existing park boundary wall to accommodate carriageway widening.\no New parallel Toucan crossing for pedestrians and cyclists across the A596, connecting Black Path to the park.\nThe Project will be delivered in two stages:\nStage 1: Design and production of Stage 2 Works Information: Administered under NEC3 ECC Option A.\nStage 2: Construction: Administered under a separate NEC3 ECC Option A.\nThere will be a decision hold-point between Stage 1 and Stage 2 where the Employer may choose to proceed, or not to proceed to Stage 2.",
"tenderPeriod": {
"endDate": "2024-09-27T12:00:00+01:00"
},
"hasRecurrence": false,
"classification": {
"id": "45000000",
"scheme": "CPV",
"description": "Construction work"
},
"submissionTerms": {
"languages": [
"en"
]
},
"submissionMethod": [
"electronicSubmission"
],
"otherRequirements": {
"requiresStaffNamesAndQualifications": true
},
"procurementMethod": "open",
"mainProcurementCategory": "works",
"submissionMethodDetails": "https://www.the-chest.org.uk",
"procurementMethodDetails": "Open procedure"
},
"parties": [
{
"id": "GB-FTS-80139",
"name": "Cumberland Council",
"roles": [
"buyer"
],
"address": {
"region": "UKD1",
"locality": "Carlisle",
"postalCode": "CA1 1RD",
"countryName": "United Kingdom",
"streetAddress": "Cumbria House, 107 - 117 Botchergate"
},
"details": {
"url": "https://www.cumberland.gov.uk/",
"buyerProfile": "https://www.cumberland.gov.uk/",
"classifications": [
{
"id": "REGIONAL_AUTHORITY",
"scheme": "TED_CA_TYPE",
"description": "Regional or local authority"
},
{
"id": "01",
"scheme": "COFOG",
"description": "General public services"
}
]
},
"identifier": {
"legalName": "Cumberland Council"
},
"contactPoint": {
"url": "https://www.the-chest.org.uk",
"email": "procurement.capital@cumberland.gov.uk"
}
},
{
"id": "GB-FTS-122338",
"name": "The High Court Of England",
"roles": [
"reviewBody"
],
"address": {
"locality": "London",
"countryName": "United Kingdom"
},
"identifier": {
"legalName": "The High Court Of England"
}
}
],
"language": "en",
"initiationType": "tender"
}