Official UK procurement notice
Construction & Capital Works Framework
Authority: Crescent Purchasing Consortium Limited (Public body)·Consortium: 2 public authorities
What is being bought45 lots · detail below
Published requirement descriptionThe Framework will provide fully compliant, flexible and streamlined access to pre-qualified construction partners for the delivery of capital works projects across the education and wider public sectors throughout the UK. It will support a broad range of new-build construction and refurbishment schemes from schools, colleges and universities to healthcare and civic infrastructure using a variety of standard forms of contract (including JCT and NEC) to suit employer preference.
The Framework covers a full range of construction and infrastructure works, including but not limited to: -
- New build projects across all parts of the public sector (e.g. education, healthcare, housing, civic, blue light)
- Refurbishment, remodelling, and retrofit
- Planned and reactive maintenance
- Enabling and demolition works
- Infrastructure and external works.
The Framework has an advertised value of £9.5billion over its 8-year term and covers projects of all values (there is no minimum or maximum value of project that can be procured through the framework).
The Framework is designed to reduce procurement burden at call-off, enable regional and project specific delivery through a lotting structure, and ensure alignment with the Procurement Act 2023, National Procurement Policy Statement (NPPS), the Construction Playbook and Gold Standard principles.
- How the procedure runs: This procurement will be conducted using a Competitive Flexible Procedure in accordance with Section 20 of the Procurement Act 2023. The procedure has been designed to ensure compliance with the Act while providing the Contracting Authority with the flexibility required to structure a process proportionate to the subject matter and complexity of this procurement. The process will comprise multiple stages: 1. Selection Stage: Bidders will be assessed to determine whether they are excluded or excludable suppliers under the Act and whether they meet the stated conditions of participation. Following evaluation, only the ten (10) highest scoring compliant bidders per Lot will be invited to progress to the next stage. 2. Dialogue Phase: Shortlisted suppliers will be invited to engage in structured dialogue to refine aspects of the procurement, including the approach to call-off contracts (based on the NEC and JCT suites), the framework conditions and the framework fee structure. 3. Final Tender Stage: Following dialogue, the Contracting Authority may issue clarifications or amendments to the procurement documents. Bidders will then be invited to submit final tenders, which will be evaluated against published qualitative and commercial criteria. 4. Award: Contracts will be awarded to the most advantageous tenders, in accordance with Section 19 of the Procurement Act 2023. This bespoke procedure is designed to balance full compliance with the Procurement Act 2023 with a streamlined, transparent, and fair process that secures the best outcomes for both Contracting Authorities and framework suppliers.
CPV: Construction work
How this framework works
From the published notice- Type
- Open framework · open framework scheme (admission reopens)
- Call-offs
- call-offs may be awarded directly or by further competition
- Bids received
- 16 bids on the busiest of 25 lots · 48 suppliers appointed
- Framework period
- 2 yrs · up to 8 yrs from 1 May 2026
- Scheme runs until
- 30 Jun 2034
- Supplier levy on call-offs (max %)
1.50% of call-off value · The Framwork Fees will be applied on a banded basis. This means that the fee percentage is applied only to the portion of the invoices raised that fall within each band, rather than applying a single percentage to the entire contract value.
The following framework fees will apply based on the value of call-off contracts awarded via the framework:-
Up to £500,000 = 1.5%
£500,001 - £2,000,000 = 1.25%
£2,000,001 - £10,000,000 = 1.1%
£10,000,001 - £25,000,000 = 0.9%
Over £25,000,000 = 0.75%
Who may buy through it
The Crescent Construction framework can be accessed by CPC Members, Crescent Services Members and any Wider Public Sector Organisation. A non-exhaustive list of Contracting Authorities permitted to call-off the framework by type is provided below for information,
- Central Government Departments, Local Government and Public Corporations
- Local Authorities
- Educational establishments in England, Wales and Scotlands including schools, academies, nurseries, Multi Academy Trusts (MATs), universities, colleges, sixth-forms
- Emergency Services including Police, Fire and Rescue Services and Ambulance Services
- NHS Bodies in England
- Hospices
- Registered Social Landlords & Housing Associations
- Third Sector and Charities
- Scottish Public Bodies
- Scottish Primary and Secondary Schools
- Scottish Special Schools
- Scottish Further Education and Higher Education
- For full details please follow this www.thecpc.ac.uk/services/eligible-pu… ↗
Published description of the framework
There are four routes to market for this framework which are the following -
- Direct Award Methodology - Ranking
This is the quickest route to contract award and is suitable where the Employer is satisfied that the highest-ranked Contractor within the relevant lot can meet the project requirements.
The Employer engages the top-ranked Contractor and, subject to agreement, proceeds directly to contract award. If the Contractor declines the opportunity, the Employer may approach the next-ranked supplier.
- Direct Award Methodology - Desktop Assessment
This option allows Employers to refine the original framework evaluation criteria to better reflect the specific requirements of their project whilst remaining within the framework's permitted parameters.
Contractors are rescored based on the adjusted criteria and the highest-scoring Contractor is identified for direct award before progressing to contract award.
- Further Competition - Full Contractor List
This approach invites all Contractors appointed to the relevant framework lot to compete for the opportunity.
The Employer develops project-specific requirements and award criteria before issuing an invitation to tender.
Contractors submit bids, which are evaluated against the Employers published award criteria, to identify the most advantageous tender before progressing to contract award.
- Restricted Further Competition
This option enables Employers to undertake a targeted competition with a reduced number of Contractors.
A desktop assessment is used to shortlist Contractors before inviting the selected organisations to submit bids. This provides a proportionate approach where a full competition may not be necessary.
Lots and requirements (45)Procurement structure
25 of 45 loaded on this pageShowing the first 25 of 45 published lots; the full list is in the JSON and Markdown mirrors of this notice. 45 lots · all with a published value · same conditions of participation on every lot · same evaluation weights on every lot.
Every one of these 25 lots carries the same published figure, £211,111,111: it is the framework's maximum for the whole notice, not each lot's own budget, and no share per lot is published. The cards below say ceiling above rather than repeat it.
Lot #1(a) - England (North) - JCT Minor Works Building Contract (MW)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #2(b) - England (North) - JCT Intermediate Building Contract (IC)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #3(c)– England (North) – JCT Design and Build Contract (D&B)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #4(d) – England North – JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #5(e) – England North – NEC 4 Engineering and Construction Short ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #6(f) – England North – NEC4 Engineering and Construction ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #7(g) – England North - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #8(h) – England North - NEC4 Engineering and Construction Contract with D&BAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #9(i) – England North - National Federation of Demolition Contractors Direct Form of ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #10(a) – England Midlands - JCT Minor Works Building Contract (MW)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #11(b) - England Midlands- JCT Intermediate Building Contract (IC)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #12(c) - England Midlands- JCT Design and Build Contract (D&B)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #13(d) – England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #14(e) - England Midlands - NEC 4 Engineering and Construction Short ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #15(f) – England Midlands - NEC4 Engineering and Construction ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #16(g) – England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #17(h) – England Midlands - NEC4 Engineering and Construction Contract with D&BAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #18(i) – England Midlands - National Federation of Demolition Contractors Direct Form of ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #19(a) – England South - JCT Minor Works Building Contract (MW)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #20(b) – England South - JCT Intermediate Building Contract (IC)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #21(c) - England South - JCT Design and Build Contract (D&B)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #22(d) – England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)AwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #23(e) - England South - NEC 4 Engineering and Construction Short ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #24(f) – England South - NEC4 Engineering and Construction ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
Lot #25(g) – England South - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractAwardedRenewalceiling above
The source published no individual description for this lot.
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
What it takes to wini
How this buyer will score bids.
The evaluation criteria and weights exactly as published on the notice, grouped by family (price, quality, social value and so on).
Evaluation split and conditions of participation as published; the tender pack may add morei
How this buyer will score bids.
The evaluation criteria and weights exactly as published on the notice, grouped by family (price, quality, social value and so on).
Published sub-criteria (2)
- Customer Requirements: 70%
- Pricing: 30%
Published award criteria (2)
- Pricing
- Customer Requirements
- Economic & financial standing
Confirmed in document pack
- Technical & professional ability
Confirmed in document pack
- Price carries 30 of 100 points: a 10% discount moves about 3 points. The method statement decides this lot, not the discount.
- “Construction & Capital Works Framework” is a framework: the contest is a place on its panel, not a single contract: call-offs may be direct or by further competition.
Price arithmetic assumes straight proportional scoring; the tender pack may use another formula.
Procedure terms & legal framework
From the official record- Procedure method
- Competitive flexible procedure
- Legal basis
- UKPGA · 2023/54 Procurement Act 2023
- Procurement category
- Works
- Notice status
- Awarded
- Procurement threshold
- Above threshold (FTS publication)
- Regulatory regime
- Standard
- Commercial structure
- Open framework scheme
- Who may use this agreement
- The Crescent Construction framework can be accessed by CPC Members, Crescent Services Members and any Wider Public Sector Organisation. A non-exhaustive list of Contracting Authorities permitted to call-off the framework by type is provided below for information, - Central Government Departments, Local Government and Public Corporations - Local Authorities - Educational establishments in England, Wales and Scotlands including schools, academies, nurseries, Multi Academy Trusts (MATs), universities, colleges, sixth-forms - Emergency Services including Police, Fire and Rescue Services and Ambulance Services - NHS Bodies in England - Hospices - Registered Social Landlords & Housing Associations - Third Sector and Charities - Scottish Public Bodies - Scottish Primary and Secondary Schools - Scottish Special Schools - Scottish Further Education and Higher Education - For full details please follow this https://www.thecpc.ac.uk/services/eligible-public-sector-bodies · open scheme: new suppliers can join during the term
- Competition type
- Competitive procedure
- GPA / WTO covered
- Unspecified in notice
- Recurring procurement
- Unspecified in notice
- First published
- 5 Aug 2025, 10:39 BST
- Last source update
- 23 Oct 2026, 13:38 BST
- Award evaluation window
- Submission end – 1 May 2026
- Authority reference
CPC/KB/02/2025- FTS notice number
2025/S 000-062263- Latest notice
- Contract details notice (UK7)
- Classification (CPV)
- Delivery area
- Official registry OCID
ocds-h6vhtk-058142Find a Tender
- How it runs
This procurement will be conducted using a Competitive Flexible Procedure in accordance with Section 20 of the Procurement Act 2023. The procedure has been designed to ensure compliance with the Act while providing the Contracting Authority with the flexibility required to structure a process proportionate to the subject matter and complexity of this procurement.
The process will comprise multiple stages:
- Selection Stage: Bidders will be assessed to determine whether they are excluded or excludable suppliers under the Act and whether they meet the stated conditions of participation. Following evaluation, only the ten (10) highest scoring compliant bidders per Lot will be invited to progress to the next stage.
- Dialogue Phase: Shortlisted suppliers will be invited to engage in structured dialogue to refine aspects of the procurement, including the approach to call-off contracts (based on the NEC and JCT suites), the framework conditions and the framework fee structure.
- Final Tender Stage: Following dialogue, the Contracting Authority may issue clarifications or amendments to the procurement documents. Bidders will then be invited to submit final tenders, which will be evaluated against published qualitative and commercial criteria.
- Award: Contracts will be awarded to the most advantageous tenders, in accordance with Section 19 of the Procurement Act 2023.
This bespoke procedure is designed to balance full compliance with the Procurement Act 2023 with a streamlined, transparent, and fair process that secures the best outcomes for both Contracting Authorities and framework suppliers.
How it was run
Official notice- Appointment period ends
- 30 Oct 2025, 17:00 GMT
- Clarification deadline
- 27 Oct 2025, 17:00 GMT
- Submission channel
- Official e-sourcing portal
- Electronic submission
- Allowed
- Accepted languages
- en
- Supplier levy on call-offs (max %)
call-off levy · 1.50% of call-off value · The Framwork Fees will be applied on a banded basis. This means that the fee percentage is applied only to the portion of the invoices raised that fall within each band, rather than applying a single percentage to the entire contract value.
The following framework fees will apply based on the value of call-off contracts awarded via the framework:-
Up to £500,000 = 1.5%
£500,001 - £2,000,000 = 1.25%
£2,000,001 - £10,000,000 = 1.1%
£10,000,001 - £25,000,000 = 0.9%
Over £25,000,000 = 0.75%
To access this opportunity, log in to suppliers.multiquote.com ↗ and view the opportunity. If you are not registered with MultiQuote, please visit suppliers.multiquote.com ↗, complete the registration form on the log in page and quote the title and reference of the notice in your registration.
Timeline
5 Aug 2025 → 23 Oct 2026 · 10 dates- Planning notice published5 Aug 2025, 10:39 BST
- Market engagement30 Aug 2025, 23:59 BST
Engagement
- Next notice expected393 days ago25 Sept 2025, 23:59 BST
- Tender notice published386 days ago3 Oct 2025, 15:45 BST
- Clarification questions by362 days ago27 Oct 2025, 17:00 GMT
- Admission / appointment period ends359 days ago · period end, not a bid countdown30 Oct 2025, 17:00 GMT
- Contract starts176 days ago1 May 2026, 00:00 BST
- Award decision expected by175 days ago1 May 2026, 23:59 BST
- Assessment summaries sent143 days ago3 Jun 2026, 00:00 BST
- Latest notice published1 day ago23 Oct 2026, 13:38 BST
Notice history
12 events · 6 releases on Find a Tender · since 5 Aug 2025- First planning notice published5 Aug 2025, 10:39 BST
- Published value updated to £9,500,000,0003 Oct 2025, 15:45 BSTwas £0
- Status changed to active3 Oct 2025, 15:45 BST
- Procurement method changed3 Oct 2025, 15:45 BST
- Deadline published: 30 Oct 2025, 17:00 GMT3 Oct 2025, 15:45 BST
- First tender notice published3 Oct 2025, 15:45 BST
- Status changed to complete12 Jun 2026, 15:42 BST
- Procurement method changed12 Jun 2026, 15:42 BST
- First award notice published12 Jun 2026, 15:42 BST
- Contract signature expected30 Jun 2026, 23:59 BSTscheduled
- Contract details notice published23 Oct 2026, 13:38 BSTUK7
- Buyer details updated23 Oct 2026, 13:38 BST
Routine re-releases (6)
- 2026-06: 1 release · 12 Jun 2026
- 2025-10: 1 release · 3 Oct 2025
- 2025-08: 1 release · 5 Aug 2025
Commercial outcome & contract awards
Published awards, contracts and bid statistics, not a forecast£211,111,111 is the framework's published maximum, restated by the publisher on 14 award rows. It is one ceiling, not 14 separate sums, and no share per lot is published; those rows read “ceiling above”.
| Awarded to | Value | Date | Status |
|---|---|---|---|
| Lot 1 · (a) - England (North) - JCT Minor Works Building Contract (MW)1 award | |||
| Aptus Construction LtdSME, EFT Construction LtdSME, Seddon Construction Limited, Senate Mech LtdSME, Walter Carefoot & Sons (Construction) LtdSME, Whitfield & Brown (Developments) LimitedSMELot: (1) Lot 1 (a) - England (North) - JCT Minor Works Building Contract (MW)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 2 · (b) - England (North) - JCT Intermediate Building Contract (IC)1 award | |||
| Aptus Construction LtdSME, Esh Construction, Frank Rogers Building Contractor LtdSME, Seddon Construction Limited, Walter Carefoot & Sons (Construction) LtdSME, Whitfield & Brown (Developments) LimitedSMELot: (2) Lot 1 (b) - England (North) - JCT Intermediate Building Contract (IC)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 10 · (a) – England Midlands - JCT Minor Works Building Contract (MW)1 award | |||
| 7 Formation Limited, Building Services NOW LtdSME, CBES Ltd, GALLAWAY CONSTRUCTION LIMITED, Seddon Construction Limited, VINCI Construction UK +1 moreLot: (10) Lot 2 (a) – England Midlands - JCT Minor Works Building Contract (MW)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 11 · (b) - England Midlands- JCT Intermediate Building Contract (IC)1 award | |||
| Building Services NOW LtdSME, CBES Ltd, ETEC CONTRACT SERVICES LTDSME, Etec Group, M & J GROUP (CONSTRUCTION & ROOFING) LTD, MBC BUILDING CONTRACTOR NW LIMITED +2 moreLot: (11) Lot 2 (b) - England Midlands- JCT Intermediate Building Contract (IC)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 12 · (c) - England Midlands- JCT Design and Build Contract (D&B)1 award | |||
| Building Services NOW LtdSME, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd, M & O BUILDING CONTRACTORS LIMITED, MY HOLDINGS GROUP LIMITED +2 moreLot: (12) Lot 2 (c) - England Midlands- JCT Design and Build Contract (D&B)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 13 · (d) – England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)1 award | |||
| Building Services NOW LtdSME, GALLAWAY CONSTRUCTION LIMITED, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd, M & J GROUP (CONSTRUCTION & ROOFING) LTD +1 moreLot: (13) Lot 2 (d) – England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 14 · (e) - England Midlands - NEC 4 Engineering and Construction Short Contract1 award | |||
| CBES Ltd, GALLAWAY CONSTRUCTION LIMITED, GRAHAM, John Graham Construction Ltd, M & J GROUP (CONSTRUCTION & ROOFING) LTD, MBC BUILDING CONTRACTOR NW LIMITED +2 moreLot: (14) Lot 2 (e) - England Midlands - NEC 4 Engineering and Construction Short Contract1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 15 · (f) – England Midlands - NEC4 Engineering and Construction Contract1 award | |||
| Building Services NOW LtdSME, CBES Ltd, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd, M & J GROUP (CONSTRUCTION & ROOFING) LTD +1 moreLot: (15) Lot 2 (f) – England Midlands - NEC4 Engineering and Construction Contract1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 16 · (g) – England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract1 award | |||
| CBES Ltd, GMI Construction Group Plc, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd, M & J GROUP (CONSTRUCTION & ROOFING) LTD +1 moreLot: (16) Lot 2 (g) – England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 17 · (h) – England Midlands - NEC4 Engineering and Construction Contract with D&B1 award | |||
| Etec Group, GALLAWAY CONSTRUCTION LIMITED, GMI Construction Group Plc, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd +2 moreLot: (17) Lot 2 (h) – England Midlands - NEC4 Engineering and Construction Contract with D&B1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 18 · (i) – England Midlands - National Federation of Demolition Contractors Direct Form of Contract1 award | |||
| DSM (DSM DEMOLITION LIMITED), DSM DemolitionSME, GLC PROJECTS LTD, MBC BUILDING CONTRACTOR NW LIMITED, MBC Building Contractors, Maylarch Environmental Ltd +1 moreLot: (18) Lot 2 (i) – England Midlands - National Federation of Demolition Contractors Direct Form of Contract1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | £211,111,110 | 3 Jun 2026 | Awarded |
| Lot 19 · (a) – England South - JCT Minor Works Building Contract (MW)1 award | |||
| 7 Formation Limited, Beard Construction, Beardwell Construction Limited, Carmelcrest Ltd, E.W. Beard Limited, Every Project Counts LtdSME +1 moreLot: (19) Lot 3 (a) – England South - JCT Minor Works Building Contract (MW)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 20 · (b) – England South - JCT Intermediate Building Contract (IC)1 award | |||
| Beard Construction, Beardwell Construction Limited, Carmelcrest Ltd, E.W. Beard Limited, ETEC CONTRACT SERVICES LTDSME, Etec Group +2 moreLot: (20) Lot 3 (b) – England South - JCT Intermediate Building Contract (IC)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 21 · (c) - England South - JCT Design and Build Contract (D&B)1 award | |||
| Beard Construction, Beardwell Construction Limited, E.W. Beard Limited, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd +2 moreLot: (21) Lot 3 (c) - England South - JCT Design and Build Contract (D&B)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
| Lot 22 · (d) – England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)1 award | |||
| Beard Construction, Beardwell Construction Limited, E.W. Beard Limited, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd +2 moreLot: (22) Lot 3 (d) – England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034Extensions: Extensions allowed: Yes (3 x 24 months) | ceiling above | 3 Jun 2026 | Awarded |
Contracts
All 18 of these contracts carry the same published figure, £211,111,111, the framework's maximum for the whole notice, not each contract's own value. They are not eleven separate sums.
Lot 1 (a) - England (North) - JCT Minor Works Building Contract (MW) · Aptus Construction LtdSME, EFT Construction LtdSME, Seddon Construction Limited, Senate Mech LtdSME, Walter Carefoot & Sons (Construction) LtdSME, Whitfield & Brown (Developments) LimitedSME
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
5 agreed KPIs: Framework Governance · Cost · Time …
- Framework Governance
- Cost
- Time
- Quality
- Management
Lot 2a JCT Minor Works Building Contract (Midlands) · 7 Formation Limited, Building Services NOW LtdSME, CBES Ltd, GALLAWAY CONSTRUCTION LIMITED, Seddon Construction Limited, VINCI Construction UK +1 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
5 agreed KPIs: Framework Governance · Cost · Time …
- Framework Governance
- Cost
- Time
- Quality
- Management
Lot 2b JCT Intermediate Building Contract (Midlands) · Building Services NOW LtdSME, CBES Ltd, ETEC CONTRACT SERVICES LTDSME, Etec Group, M & J GROUP (CONSTRUCTION & ROOFING) LTD, MBC BUILDING CONTRACTOR NW LIMITED +2 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
5 agreed KPIs: Framework Governance · Cost · Time …
- Framework Governance
- Cost
- Time
- Quality
- Management
Lot 2c JCT Design and Build Contract (Midlands) · Building Services NOW LtdSME, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd, M & O BUILDING CONTRACTORS LIMITED, MY HOLDINGS GROUP LIMITED +2 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
5 agreed KPIs: Framework Governance · Cost · Time …
- Framework Governance
- Cost
- Time
- Quality
- Management
Lot 2d JCT D&B Contract with PCSA (Midlands) · Building Services NOW LtdSME, GALLAWAY CONSTRUCTION LIMITED, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd, M & J GROUP (CONSTRUCTION & ROOFING) LTD +1 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 2e NEC 4 Short Form (Midlands) · CBES Ltd, GALLAWAY CONSTRUCTION LIMITED, GRAHAM, John Graham Construction Ltd, M & J GROUP (CONSTRUCTION & ROOFING) LTD, MBC BUILDING CONTRACTOR NW LIMITED +2 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 2f NEC 4 Engineering Contract · Building Services NOW LtdSME, CBES Ltd, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd, M & J GROUP (CONSTRUCTION & ROOFING) LTD +1 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 2g NEC 4 Eng Contract with PS (Midlands) · CBES Ltd, GMI Construction Group Plc, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd, M & J GROUP (CONSTRUCTION & ROOFING) LTD +1 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 2h NEC 4 Engineering and Constr. Contract with D&B (Midlands) · Etec Group, GALLAWAY CONSTRUCTION LIMITED, GMI Construction Group Plc, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd +2 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 2i Demolition Contract (Midlands) · DSM (DSM DEMOLITION LIMITED), DSM DemolitionSME, GLC PROJECTS LTD, MBC BUILDING CONTRACTOR NW LIMITED, MBC Building Contractors, Maylarch Environmental Ltd +1 more
- Signed
- 1 Jul 2026
- Value
- £211,111,110
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 3a JCT Minor Works Building Contract (South) · 7 Formation Limited, Beard Construction, Beardwell Construction Limited, Carmelcrest Ltd, E.W. Beard Limited, Every Project Counts LtdSME +1 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 1b JCT Intermediate Building Contract (IC) · Aptus Construction LtdSME, Esh Construction, Frank Rogers Building Contractor LtdSME, Seddon Construction Limited, Walter Carefoot & Sons (Construction) LtdSME, Whitfield & Brown (Developments) LimitedSME
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 3b JCT Intermediate Building Contract (South) · Beard Construction, Beardwell Construction Limited, Carmelcrest Ltd, E.W. Beard Limited, ETEC CONTRACT SERVICES LTDSME, Etec Group +2 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 3c JCT Design and Build Contract (South) · Beard Construction, Beardwell Construction Limited, E.W. Beard Limited, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd +2 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 3d JCT D&B Contract with PCSA (South) · Beard Construction, Beardwell Construction Limited, E.W. Beard Limited, GRAHAM, Galliford Try Construction Limited, John Graham Construction Ltd +2 more
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 3e NEC 4 Short Form (South)
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 3f NEC 4 Engineering Contract
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 3g NEC 4 Eng Contract with PS (South)
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 3h NEC 4 Engineering and Constr. Contract with D&B (South)
- Signed
- 1 Jul 2026
- Value
- ceiling above
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Lot 3i Demolition Contract (South)
- Signed
- 1 Jul 2026
- Value
- £211,111,110
- Period
- 1 Jul 2026 – 30 Jun 2028 · up to 30 Jun 2034 with extensions
- Status
- active
- Extensions
- The Framework may be extended by CPC in accordance with its terms, subject to satisfactory supplier performance, continued operational and commercial requirements and CPC being satisfied that extension remains appropriate. Any extension will be exercised at CPC's discretion and in accordance with the provisions of the Framework.
Bid statistics published by the authority
| Lot | Bids | SME | VCSE | Valid bid range |
|---|---|---|---|---|
| 1 · (a) - England (North) - JCT Minor Works Building Contract (MW) | 11final-stage tenders | 3 | 0 | — |
| 2 · (b) - England (North) - JCT Intermediate Building Contract (IC) | 16final-stage tenders | 3 | 0 | — |
| 3 · (c)– England (North) – JCT Design and Build Contract (D&B) | 10final-stage tenders | 0 | 0 | — |
| 4 · (d) – England North – JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA) | 11final-stage tenders | 2 | 0 | — |
| 5 · (e) – England North – NEC 4 Engineering and Construction Short Contract | 12final-stage tenders | 3 | 0 | — |
| 6 · (f) – England North – NEC4 Engineering and Construction Contract | 8final-stage tenders | 2 | 0 | — |
| 7 · (g) – England North - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract | 10final-stage tenders | 2 | 0 | — |
| 8 · (h) – England North - NEC4 Engineering and Construction Contract with D&B | 10final-stage tenders | 1 | 0 | — |
| 9 · (i) – England North - National Federation of Demolition Contractors Direct Form of Contract | 6final-stage tenders | 0 | 0 | — |
| 10 · (a) – England Midlands - JCT Minor Works Building Contract (MW) | 11final-stage tenders | 0 | 0 | — |
| 11 · (b) - England Midlands- JCT Intermediate Building Contract (IC) | 11final-stage tenders | 1 | 0 | — |
| 12 · (c) - England Midlands- JCT Design and Build Contract (D&B) | 8final-stage tenders | 0 | 0 | — |
| 13 · (d) – England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA) | 9final-stage tenders | 0 | 0 | — |
| 14 · (e) - England Midlands - NEC 4 Engineering and Construction Short Contract | 8final-stage tenders | 1 | 0 | — |
| 15 · (f) – England Midlands - NEC4 Engineering and Construction Contract | 10final-stage tenders | 1 | 0 | — |
| 16 · (g) – England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract | 8final-stage tenders | 1 | 0 | — |
| 17 · (h) – England Midlands - NEC4 Engineering and Construction Contract with D&B | 8final-stage tenders | 1 | 0 | — |
| 18 · (i) – England Midlands - National Federation of Demolition Contractors Direct Form of Contract | 6final-stage tenders | 1 | 0 | — |
| 19 · (a) – England South - JCT Minor Works Building Contract (MW) | 8final-stage tenders | 2 | 0 | — |
| 20 · (b) – England South - JCT Intermediate Building Contract (IC) | 11final-stage tenders | 3 | 0 | — |
| 21 · (c) - England South - JCT Design and Build Contract (D&B) | 12final-stage tenders | 1 | 0 | — |
| 22 · (d) – England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA) | 10final-stage tenders | 1 | 0 | — |
| 23 · (e) - England South - NEC 4 Engineering and Construction Short Contract | 9final-stage tenders | 2 | 0 | — |
| 24 · (f) – England South - NEC4 Engineering and Construction Contract | 9final-stage tenders | 2 | 0 | — |
| 25 · (g) – England South - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract | 9final-stage tenders | 2 | 0 | — |
Who bid
- wonAptus Construction LtdSME · North East England · 1, 2, 5, 6, 7, 8
- wonGLC PROJECTS LTD · North East England · 1, 3, 5, 9, 10, 12, 14, 18, Lot 27, Lot 36, Lot 37, Lot 39, Lot 41, Lot 45
- did not winCompass Developments (NE) LtdSME · North East England · 1, 2, 4, 5
- did not winBrims Construction Ltd · North East England · 1, 2, 4, 8
- wonWalter Carefoot & Sons (Construction) Ltd.SME · North West England · 1, 2, 3
- did not winRosslee Construction LtdSME · North West England · 1, 2, 4, 5, 6, 7
- wonSenate Mech LtdSME · North West England · 1, 2, 5
- wonWhitfield & Brown (Developments) LtdSME · North West England · 1, 2, 4
- wonEFT Construction LtdSME · North West England · 1, 2, 3, 6
- wonSeddon Construction Limited · North West England · 1, 2, 3, 4, 5, 6, 7, 8, 10, 11, 12, 13, 14, 15, 16, 17
- wonFRANK ROGERS (BUILDING CONTRACTOR) LIMITEDSME · North West England · 1, 2, 3, 6, 8, 12, 21
- did not winJupiter Construction LTD · Yorkshire and the Humber · 2, 3
- did not winWillliam Birch & Sons Ltd · Yorkshire and the Humber · 2, 5, 7, 8
- did not winASHFIELD PROJECTS (YORKSHIRE) LTD · Yorkshire and the Humber · 2, 3
- wonEsh Construction Limited · North East England · 2, 4, 5, 7, 8
- won7 FORMATION LIMITED · East Midlands · 2, 10, 11, 19, 20, 21, Lot 28, Lot 29, Lot 30, Lot 37, Lot 38, Lot 39
- did not winNRC Services Limited · Yorkshire and the Humber · 2, 6
- wonGRAHAM · Northern Ireland · all lots
- wonMYC Group Ltd · Greater London · 3, 4, 12, 13, 21, 22
- wonGalliford Try Construction Limited · Greater London · all lots
- wonGALLAWAY CONSTRUCTION LIMITED · North West England · 4, 8, 10, 11, 13, 14, 15, 17, Lot 28, Lot 29, Lot 30, Lot 31, Lot 32, Lot 33, Lot 35
- did not winAREA · Greater London · 4, 13, 21, 22, Lot 30, Lot 31, Lot 39, Lot 40
- did not winJohn Turner Construction Group LtdSME · North West England · 5
- wonCBES · Scotland · 5, 7, 10, 11, 14, 15, 16, Lot 37, Lot 38, Lot 39, Lot 40, Lot 41, Lot 42, Lot 43, Lot 44
- wonMBC Building Contractors · North West England · 5, 9, 10, 11, 14, 18
- did not winPremier Modular Ltd · Yorkshire and the Humber · 7, 16, 23, 25, Lot 26, Lot 30, Lot 31, Lot 32, Lot 33, Lot 34, Lot 39, Lot 40, Lot 41, Lot 42, Lot 43
- wonGMI CONSTRUCTION GROUP PLC · Yorkshire and the Humber · 7, 8, 16, 17
- wonRHODAR INDUSTRIAL SERVICES LIMITED · Yorkshire and the Humber · 9, 18, Lot 27, Lot 36, Lot 45
- did not winPLANET INTERIOR PROJECTS LIMITED · North West England · 9, 11, 15, 18, Lot 28, Lot 29, Lot 30, Lot 31, Lot 32, Lot 33, Lot 34, Lot 35, Lot 36
- wonDSM (DSM DEMOLITION LIMITED) · West Midlands · 9, 18, Lot 27
- did not winA.BUCKLER HAULAGE LIMITEDSME · North East England · 9
- did not winA.R. CARTWRIGHT (CONSTRUCTION) LIMITED · West Midlands · 10, 11
- wonBSN Group Construction LtdSME · West Midlands · 10, 11, 12, 13, 15
- wonM & J Group (Construction & Roofing) Ltd. · East of England · 10, 11, 13, 14, 15, 16, 17, 21, 22, 23, 24, 25, Lot 26
- wonVINCI Facilities · Greater London · 10, 23, 25, Lot 28, Lot 29, Lot 31, Lot 32, Lot 33, Lot 34
- wonM & O BUILDING CONTRACTORS LIMITED · East Midlands · 10, 11, 12, 13, 15, 17
- wonEtec Group · Greater London · 11, 14, 15, 16, 17, 20, 23, 24, 25, Lot 26, Lot 28, Lot 29, Lot 30, Lot 31, Lot 32, Lot 33, Lot 34, Lot 35
- wonMaylarch Environmental Ltd · South East England · 18, Lot 27
- wonEvery Project Counts LtdSME · East of England · 19, 20, 21
- did not winStandage & Co. LimitedSME · Greater London · 19, 20, 21, 22
- wonBeardwell Construction Ltd · East of England · 19, 20, 21, 22, 23, 24, Lot 26
- wonCarmelcrest Limited · East of England · 19, 20, 22, 23, 24, 25, Lot 26, Lot 27
- did not winTOTAL PROTECTION (CONTRACTING SERVICES) LTD · East of England · 19, 20
- wonMulalley and Company Ltd · Greater London · 19, 20, 21, 22, 24, Lot 26
- wonBeard Construction · South West England · 19, 20, 21, 22, 23, 24, 25, Lot 26
- wonKnightsbridge Property Services LtdSME · Greater London · 20, 23, 24
- did not winC.G. FRY AND SON LIMITED · South West England · 20
- did not winCITYAXIS LIMITEDSME · Greater London · 25, Lot 26
- did not winD R W LTD. · Scotland · Lot 37, Lot 38, Lot 39, Lot 41, Lot 42, Lot 44
- did not winCCG (SCOTLAND) LIMITED · Scotland · Lot 39, Lot 40, Lot 42, Lot 43, Lot 44
Bidders as named on the Procurement Act 2023 award notice. “Won” means the bidder holds an award on this notice.
Contracting authority & participating public bodies
2 public bodies on the noticeConsortium members and other public bodies
- Crescent Purchasing Consortium LimitedContracting authorityPublic undertaking
Framework contractors & participating bidders
90 commercial parties on the notice · 47 awardedThe first 50 of 90 commercial parties (by name); the JSON mirror lists them all.
- 7 FORMATION LIMITEDFramework contractor
- 7 FORMATION LIMITEDFramework contractor
- A.BUCKLER HAULAGE LIMITEDFramework contractor
- A.BUCKLER HAULAGE LIMITEDFramework contractor
- A.R. CARTWRIGHT (CONSTRUCTION) LIMITEDBidder / tenderer
- APTUS CONSTRUCTION LIMITEDFramework contractor
- AREAFramework contractor
- AREA SQ. LIMITEDFramework contractor
- ASHFIELD PROJECTS (YORKSHIRE) LTDFramework contractor
- ASHFIELD PROJECTS (YORKSHIRE) LTDFramework contractor
Show 40 more suppliers
- Aptus Construction LtdFramework contractor
- BEARDWELL CONSTRUCTION LIMITEDFramework contractor
- BSN GROUP CONSTRUCTION LIMITEDFramework contractor
- BSN Group Construction LtdFramework contractor
- Beard ConstructionFramework contractor
- Beardwell Construction LtdFramework contractor
- Brims Construction LtdBidder / tenderer
- C.G. FRY AND SON LIMITEDBidder / tenderer
- CARMELCREST LIMITEDFramework contractor
- CBESFramework contractor
- CBES LIMITEDFramework contractor
- CCG (SCOTLAND) LIMITEDFramework contractor
- CCG (SCOTLAND) LIMITEDFramework contractor
- CITYAXIS LIMITEDFramework contractor
- CITYAXIS LIMITEDFramework contractor
- COMPASS DEVELOPMENTS (NE) LTDFramework contractor
- Carmelcrest LimitedFramework contractor
- Compass Developments (NE) LtdFramework contractor
- D R W LTD.Framework contractor
- D R W LTD.Framework contractor
- DSM (DSM DEMOLITION LIMITED)Framework contractor
- DSM DEMOLITION LIMITEDFramework contractor
- E.W. BEARD LIMITEDFramework contractor
- EFT CONSTRUCTION LIMITEDFramework contractor
- EFT Construction LtdFramework contractor
- ESH CONSTRUCTION LIMITEDFramework contractor
- ETEC CONTRACT SERVICES LIMITEDFramework contractor
- EVERY PROJECT COUNTS LTDFramework contractor
- Esh Construction LimitedFramework contractor
- Etec GroupFramework contractor
- Every Project Counts LtdFramework contractor
- FRANK ROGERS (BUILDING CONTRACTOR) LIMITEDFramework contractor
- FRANK ROGERS (BUILDING CONTRACTOR) LIMITEDFramework contractor
- GALLAWAY CONSTRUCTION LIMITEDFramework contractor
- GALLAWAY CONSTRUCTION LIMITEDFramework contractor
- GALLIFORD TRY CONSTRUCTION LIMITEDFramework contractor
- GLC PROJECTS LTDFramework contractor
- GLC PROJECTS LTDFramework contractor
- GMI CONSTRUCTION GROUP PLCFramework contractor
- GMI CONSTRUCTION GROUP PLCFramework contractor
Official documents & specifications (228)
Official links; attachments are not copiedNotices published for this procedure
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
Show 22 more notices
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
- Contract details notice Contract details notice on Find a Tender
198 further documents are listed in the JSON mirror.